(55 ILCS 5/5‑32001)(from Ch. 34, par. 5‑32001) Sec. 5‑32001. Right to make local improvements. Any county may make a local improvement outside of a municipality, as defined in Section 1‑1‑2 of the "Illinois Municipal Code", whenever the public necessity requires such improvement, subject only to the limitations prescribed in this Division. This Division shall not be construed as repealing any other laws with respect to county government, but shall be considered as an additional grant of power for the purposes herein set out. Any number of streets, avenues, lanes or alleys, sidewalks, or any other public places, or parts thereof, or private roads or streets, in platted subdivisions of the county to be improved may be included in one proceeding, as provided in this Division, even though they may be intersected by previously improved streets, avenues, roads or alleys which are not included in the proceeding, where they are contiguous or part of a connected system with reciprocal benefits. This Division shall not be construed to limit the powers of municipalities contained in Article 11 of the Illinois Municipal Code. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32002)(from Ch. 34, par. 5‑32002) Sec. 5‑32002. Definitions. In this Division the following terms have the meanings ascribed to them unless the context indicates otherwise: "Local improvements" means the constructing, installing, improving or extending of storm sewers, sanitary sewers or water mains; the improving, widening, extending or repairing of any street, highway, road, boulevard, alley, sidewalk or other public way; the constructing, installing or repairing of curbs, gutters, street lights and all necessary appurtenances thereto; or any combination thereof, within or abutting on any platted subdivision either prior to or after any structures are placed within such platted subdivision. "Platted subdivision" is any described tract of land which has been divided into 2 or more lots or parcels which involved the creation of a new street and which has been recorded. "County" means any county in this State which is not a home rule unit. "Attorney" means the attorney employed by the county committee of local improvements to furnish the necessary legal services in connection with any local improvement to be constructed under this Division. "Engineer" means the engineer employed by the county committee of local improvements to prepare the necessary plans, estimates and specifications, and supervise construction of any local improvement to be constructed under this Division. "Committee" means the Committee of Local Improvements created by this Division. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32003)(from Ch. 34, par. 5‑32003) Sec. 5‑32003. Committee of local improvements. There is created the Committee of Local Improvements consisting of the presiding officer of the County Board, or some person designated by him as his representative for the purposes of this Committee, the county engineer or superintendent of highways or administrative head of the county department of public works as determined by such presiding officer, and 3 members of the County Board appointed by the presiding officer of the county board with the advice and consent of the county board. The Committee shall elect from its members a president, except that the Chairman or President of the County Board, or his representative, as the case may be is prohibited from serving in that capacity. The county board shall provide by resolution for compensation not to exceed $15 per day for each member while performing his duties as a member of the Committee. The Committee may employ a secretary who shall keep the minutes of the Committee's proceedings and be the custodian of all papers pertaining to the business of the Committee and shall perform all other duties the Committee prescribes. (Source: P.A. 86‑962; 87‑217.)
(55 ILCS 5/5‑32004)(from Ch. 34, par. 5‑32004) Sec. 5‑32004. Origination of local improvements. The Committee may originate a local improvement as defined in this Division anywhere in the county outside of a municipality, as defined in Section 1‑1‑2 of the "Illinois Municipal Code", as amended, such improvement to be paid for by special assessment, either with or without a petition, by the adoption of a resolution describing the local improvement abutting or within the platted subdivision to be so improved. This resolution shall be at once transcribed into the records of the Committee and shall be presented to the members of the county board at any regularly scheduled meeting accompanied by a recommendation from the Committee for the adoption of a resolution by the county board describing the public way to be so improved. A resolution adopted without a petition shall be revoked by the county board without further action on the improvement sought if the owners of record of more than one‑half of the property abutting on or within any platted subdivision located outside the boundaries of a municipality object, by petition, by individual objections in writing, or by a combination of petitions and individual objections. Objections and petitions against an improvement shall be filed within 30 days of notification to the owners of record of the assessment. Proceedings to make a local improvement also may be instituted whenever the owners of record of one‑half the property abutting on or within any platted subdivision located outside the boundaries of a municipality, petitions the Committee of the county for a local improvement thereon. The Committee shall present such petition to the members of the county board at a regularly scheduled meeting, and recommend the adoption of a resolution by the board describing the public way to be so improved. If the resolution is so adopted by the county board, the Committee of local improvements shall proceed with all of the necessary steps for the improvement. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32005)(from Ch. 34, par. 5‑32005) Sec. 5‑32005. Applicability of Division. The provisions of this Division may be made applicable to improvement of a private street or road upon petition signed by 3/5 of the owners of record of properties abutting or served by such private street or roadway. The petition shall be filed with the Committee and is subject to the provisions of Section 5‑32004 and subsequent provisions of the Division. Upon completion of the improvement, the improvement is to be incorporated into the township or district road system as provided in Section 6‑325 of the Illinois Highway Code. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32006)(from Ch. 34, par. 5‑32006) Sec. 5‑32006. Public hearing on resolution. After the adoption of the resolution for a local improvement as provided for in this Division, the Committee by a resolution shall fix a day and hour for a public hearing thereon. The hearing shall be not less than 10 days after the adoption of the resolution. The Committee shall also have an estimate of the cost of the improvement made in writing and signed by the president. This estimate shall be itemized to the satisfaction of the Committee and shall be made a part of the records of the resolution. Notice of the time, place and hour of the proposed hearing shall be sent by mail directed to all persons who paid the general taxes for the last preceding year on each lot, block, tract or parcel of land fronting on the proposed improvement and to all municipalities the boundaries of which lie within one and one‑half miles from the location of the proposed local improvement not less than 5 days prior to the time set for the public hearing. These notices shall contain 1. The substance of the resolution adopted by the Committee; 2. The estimate of the cost of the proposed improvement; 3. A notification that the nature, extent, kind, character and the estimated cost of the proposed improvement may be changed by the Committee at the public hearing thereon. If, upon the hearing the Committee considers the proposed improvement desirable it shall adopt a resolution and prepare and submit an ordinance therefor. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32007)(from Ch. 34, par. 5‑32007) Sec. 5‑32007. Conduct of public hearing. At the time and place fixed in the specified notice for the public hearing, the Committee shall meet and hear the representations of any person desiring to be heard on the subject of the necessity for the proposed improvement, the nature thereof, or the cost as estimated. In case any person appears to object to the proposed improvement or any of the elements thereof at the public hearing the Committee shall adopt a new resolution abandoning the proposed improvement or adhering thereto or changing, altering or modifying the extent, nature, kind, character and estimated cost provided the change does not increase the estimated cost of the improvement to exceed 20% of such cost without a further public hearing thereon as it considers most desirable. Thereupon, if the proposed improvement is not abandoned, the Committee shall have an ordinance prepared to be submitted to the county board at a regularly scheduled meeting. This ordinance shall prescribe the nature, character, locality and description of the improvement and shall provide that the improvement shall be made wholly by special assessment of contiguous abutting property. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32008)(from Ch. 34, par. 5‑32008) Sec. 5‑32008. Recommendation of improvement. Accompanying any ordinance for a local improvement presented by the Committee shall be a recommendation of such improvement by the Committee signed by at least a majority of the members thereof. The recommendation by the Committee shall be prima facie evidence that all of the requirements of the law have been complied with. If a variance is shown in the proceedings in the Court it shall not affect the validity of the proceedings unless the court considers the variance willful or substantial. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32009)(from Ch. 34, par. 5‑32009) Sec. 5‑32009. Estimate of cost of improvement. An estimate of the cost of the improvement including the cost of engineering services as originally contemplated or as changed, altered, or modified at the public hearing itemized so far as the Committee thinks necessary shall be presented along with the ordinance and the recommendation. This estimate of cost shall be presented over the signature of the President of the Committee, who shall certify that, in his opinion, the estimate of cost does not exceed the probable cost of the improvement proposed and lawful expenses attending the improvement. The recommendation by the Committee shall be prima facie evidence that it is based upon full compliance with the requirements of the Division. No ordinance for any local improvement to be paid for by special assessment shall be considered or passed as provided for herein unless the ordinance is first recommended by the Committee. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32010)(from Ch. 34, par. 5‑32010) Sec. 5‑32010. Petition for levy of special assessment. Upon the passage of any ordinance for a local improvement pursuant thereto, a petition shall be filed in the circuit court in the county where the affected territory lies praying that steps be taken to levy a special assessment for the improvement in accordance with the provisions of that ordinance. There shall be attached to or filed with this petition a certified copy of the ordinance and a copy of the recommendation of the Committee and the estimate of cost as approved. The failure to file any or either of these copies shall not affect the jurisdiction of the court to proceed in the cause and to act upon the petition, but if it appears in any such cause that the copies have not been attached to or filed with the petition, before the filing of the assessment roll therein, then upon motion of any objector for that purpose on or before appearance day in the cause the entire petition and the proceedings shall be dismissed. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32011)(from Ch. 34, par. 5‑32011) Sec. 5‑32011. Manner of assessment. Upon the filing of such a petition the President of the Committee shall appoint some competent person who is a resident and elector of the county to make a true and impartial assessment of, the cost of the specified improvement upon the property benefited by the improvement. The levying officer shall apportion and assess the amount found to be of benefit to the property contiguous or abutting upon the improvement upon the several lots, blocks, tracts and parcels of land in the proportion in which they will severally be benefited by the improvement. No lot, block, tract or parcel of land shall be assessed a greater amount than it will actually be benefited. In levying any special assessment each lot, block, tract or parcel of land shall be assessed separately in the same manner as upon the assessment for general taxation. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32012)(from Ch. 34, par. 5‑32012) Sec. 5‑32012. Assessment roll. The assessment and the amount as found by the levying officer shall be known as the assessment roll. It shall contain, 1. A list of all of the lots, blocks, tracts and parcels of land assessed for the proposed improvement; 2. The amount assessed against each; 3. The name of the person who paid the taxes on each such parcel during the last preceding calendar year, in which taxes were paid as ascertained upon investigation by the levying officer making the return or under his direction; 4. The residence of the person so paying the taxes on each such parcel if the residence on diligent inquiry can be found; 5. The amount of each installment shall also be stated. The levying officer making the roll shall certify under oath that he believes that the amount assessed against each parcel of property is just and equitable and does not exceed the benefit which in each case will be derived from the improvement, and that no lot, block, tract or parcel of land has been assessed more than its proportionate share of the cost of the improvement. Each lot or part of land owned and improved as one parcel may be assessed as one parcel. Notice shall be given by the levying officer of the nature of the improvement, of the pendency of the proceedings, of the time and place of the filing of the petition therefor, of the time and place of the filing of the assessment roll and of the time and place at which application will be made for the confirmation of assessment, the same to be not less than 15 days after the mailing of such notices. Notices shall be sent by mail postage prepaid to each of the specified persons paying taxes on the respective parcels during the last preceding year during which taxes were paid at his residence as shown on the Assessment Roll. The notice shall include the legal description of the property assessed, the amount assessed to the person to whom it is directed for the improvement proposed and the total amount of the improvement. An affidavit shall be filed before the final hearing showing a compliance by the levying officer with the requirements of this Division, and also showing that the levying officer or some one acting under his direction made a careful examination of the collector's books, showing the payment of general taxes during the last preceding year in which the taxes were paid thereon, to ascertain the person who last paid the taxes on the respective parcel and a diligent search for his residence and that the report clearly states the person and residence as ascertained by the affiant. This report and affidavit shall be sufficient evidence for the purpose of this proceeding of the correctness of the assessment roll in these particulars. In case the affidavit is found in any respect willfully false, the person making it is guilty of perjury. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32013)(from Ch. 34, par. 5‑32013) Sec. 5‑32013. Installments; interest. The ordinance provided for in this Division shall provide that the aggregate amounts assessed in each individual assessment shall be divided into installments not more than 10 in number. Such division shall be made so that all installments shall be equal in amount except that all fractional amounts shall be added to the first installment so as to leave the remaining of the aggregate equal in amount and each a multiple of $100. The first installment shall be due and payable on January 2 next, after the date of the first voucher issued on account of construction work done, and the second installment one year thereafter and so on annually until all installments are paid. The Committee shall file in the office of the Clerk of the Circuit Court in which such assessment was confirmed a certificate signed by its secretary of the date of the first voucher and the amount thereof within 30 days after the issuance thereof. All installments shall bear interest as hereinafter provided until paid at the rate of not to exceed 7% annually. Interest on assessments shall begin to run from the date of the first voucher issued on account of construction work done. The interest on each installment shall be paid as follows: On January 2, next succeeding the date of the first voucher as certified the interest accruing up to that time on all unpaid installments shall be due and payable with the installment, and thereafter the interest on all unpaid installments then payable shall be payable annually and be collected therewith. In all cases the County Collector, whenever payment is made on any installment, shall collect interest thereon up to the date of such payment whether the payment be made at or after maturity. Any person may at any time pay the whole assessment against any lot, piece or parcel of land or any installment thereof with interest as herein provided up to the date of the payment. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32014)(from Ch. 34, par. 5‑32014) Sec. 5‑32014. Special assessment notice. The Committee in addition to the notice in this Division provided for shall publish a notice at least twice not more than 30 days nor less than 15 days in advance of the time at which the confirmation of the specified assessment is to be sought, in one or more newspapers published in the county or if no newspaper is published therein then in one or more newspapers with a general circulation in the county. The notice shall be over the name of the levying officer and shall be substantially as follows:
"SPECIAL ASSESSMENT NOTICE
Notice is hereby given to all persons interested that the County of .... has order that (herein insert a brief description of the nature of the improvement), the ordinance for the improvement being on file in the office of the County Clerk, having applied to the Circuit Court of .... County, for an assessment of the costs of the improvement according to benefits an assessment therefor having been made and returned to that Court, a final hearing thereon will be had on (insert date), or as soon thereafter as the business of the Court will permit. All persons desiring may file objections in that Court before that day and may appear on the hearing and make their defense. (Here give date)NAME.... (LEVYING OFFICER)."The number of installments and the rate of interest also shall be stated. (Source: P.A. 91‑357, eff. 7‑29‑99.)
(55 ILCS 5/5‑32015)(from Ch. 34, par. 5‑32015) Sec. 5‑32015. Extension of time for filing objections. If 15 days have not elapsed between the first publication and the day fixed in the notice for filing objections, the cause shall be continued for 15 days, and time for filing objections shall be correspondingly extended. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32016)(from Ch. 34, par. 5‑32016) Sec. 5‑32016. Filing objections to report; default. Any person interested in any real estate to be affected by an assessment, may appear and file objections to the report by the time mentioned in the specified notice, or in case of incomplete notice than as specified in Section 5‑32015, or within such further time as the court may allow. The court may make an order in regard to the time of filing these objections but no prior rule need be taken therefor unless directed by the court. As to all lots, blocks, tracts and parcels of land, to the assessment of which objections are not filed within the specified time, or such other time as may be ordered by the court, default may be entered and the assessment may be confirmed by the court, notwithstanding the fact that objections may be pending and undisposed of as to other property. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32017)(from Ch. 34, par. 5‑32017) Sec. 5‑32017. Inquiries; powers of court. Upon objections or motions for that purpose, the court in which the specified proceeding is pending may inquire in a summary way whether the officer making roll has omitted any property benefited, and whether or not the assessment as made and returned is an equitable and just distribution of the cost of the improvement among the parcels of property assessed. The court has the power upon such application being made, to revise and correct the assessment levied or to change the manner of distribution among the parcels of private property, so as to produce a just and equitable assessment. The court may either make such corrections or change or determine in general the manner in which the corrections or changes shall be made and refer the assessment roll back to the levying officer for revisions, corrections or alterations in such manner as the court may determine. (Source: P.A. 91‑357, eff. 7‑29‑99.)
(55 ILCS 5/5‑32018)(from Ch. 34, par. 5‑32018) Sec. 5‑32018. Hearing. On the application of the petitioner, at any time after the return day, the court may set down all objections, except the objection that the property of the objector will not be benefited to the amount assessed against it, and that it is assessed more than its proportionate share of the cost of the improvement, for a hearing at a time to be fixed by the court. Upon this hearing the court shall determine all questions relating to the sufficiency of the proceedings and of the benefits between the different parcels of property assessed, together with all other questions arising in that proceeding, with the exception specified, and shall thereupon enter an order in accordance with the conclusions it reaches. But this order shall not be a final disposition of any of these questions for the purpose of appeal, unless the objectors waive further controversy as to the remaining question upon the record. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32019)(from Ch. 34, par. 5‑32019) Sec. 5‑32019. Proceedings. If it is objected to on the part of any property assessed for such an improvement, that it will not be benefited thereby to the amount assessed thereon, and that it is assessed more than its proportionate share of the cost of the improvement, and a jury is not waived by agreement of the parties, the court shall impanel a jury to try that issue. In that case unless otherwise ordered by the court, all such objections shall be tried and disposed of before a single jury. The assessment roll, as returned by the officer who made it, or as revised and corrected by the court on the hearing of the legal objections, shall be prima facie evidence of the correctness of the amount assessed against each objected owner but shall not be counted as the testimony of any witness or witnesses in the cause. That assessment roll may be submitted to the jury and may be taken into the jury room by the jury when it retires to deliberate on its verdict. Either party may introduce such other evidence as may bear upon that issue or issues. The hearing shall be conducted as in other civil cases. If it appears that the property of any objector is assessed more than it will be benefited by the specified improvement, or more than its proportionate share of the cost of the improvement, the jury shall so find, and it shall also find the amount for which that property ought to be assessed, and judgment shall be rendered accordingly. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32020)(from Ch. 34, par. 5‑32020) Sec. 5‑32020. Distribution of deficiency. Whenever, on a hearing by the court or before a jury, the amount of any assessment is reduced or cancelled, so that there is a deficiency in the total amount remaining assessed in the proceeding, the court may, in the same proceeding, distribute this deficiency upon the other property in the district assessed, in such manner as the court finds just and equitable, not exceeding, however, the amount such property will be benefited by the specified improvement. In case any portion of this deficiency is charged against such property not represented in court, a new notice, of the same nature as the original notice, shall be given in like manner as the original notice, to show the cause why the assessment, as thus increased, should not be confirmed. The owners of or parties interested in such property have the right to object in the same form and with the same effect as in case of the original assessment, and the court has the same power to dispose thereof. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32021)(from Ch. 34, par. 5‑32021) Sec. 5‑32021. Time for hearing. The hearing in all the cases arising under this Division, may be had at such time as the court may designate, and such proceedings shall have precedence over all other cases in any court, where they are brought, except criminal cases, or other cases in which the public is a moving party. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32022)(from Ch. 34, par. 5‑32022) Sec. 5‑32022. Additional powers of court. The court before which any such proceedings may be pending may modify, alter, change, annul, or confirm any assessment returned as specified, in addition to the authority already conferred upon it, and may take all such proceedings, and make all such orders, as may be necessary to the improvement, according to the principles of this Division, and may from time to time, as may be necessary, continue the application for that purpose as to the whole or any part of the premises. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32023)(from Ch. 34, par. 5‑32023) Sec. 5‑32023. Effect of similar improvements previously made in same locality. It is no objection to the legality of any local improvement that a similar improvement has been previously made in the same locality, if the ordinance therefor is recommended by the Committee as above provided, but nothing contained in this Division shall interfere with any defense in this proceeding relating to the benefits received therefrom. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32024)(from Ch. 34, par. 5‑32024) Sec. 5‑32024. Confirmation of assessment roll. In case of a special assessment to be paid by installments under the provisions of this Division, the order of confirmation that is entered upon the return of the assessment roll shall apply to all of the installments thereof, and may be entered in one order. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32025)(from Ch. 34, par. 5‑32025) Sec. 5‑32025. Review; effect of judgments. The judgments of the court shall be final as to all the issues involved, and the proceedings in the specified cause shall be subject to review by appeal as provided in this Division and not otherwise. However, by mutual consent such a judgment may be vacated or modified notwithstanding the expiration of 30 days from the rendition of the judgment, except as provided in this Division. Such judgment shall have the effect of several judgments as to each tract or parcel of land assessed, and no appeal from any such judgment shall invalidate or delay the judgments, except as to the property concerning which the appeal is taken. Such judgment shall be a lien on behalf of the county making any improvement, for the payment of which the special assessment is levied, on the property assessed from the date thereof, to the same extent and of equal force and validity as a lien for the general taxes until the judgment is paid or the property against which any such judgment is entered is sold to pay the judgment. Nothing in this Division shall interfere with the right of the petitioner to dismiss its proceedings, and for that purpose to vacate such a judgment at its election at any time before commencing the actual collection of the assessment. The court in which the judgment is rendered shall enter an order vacating or annulling the judgment of confirmation on motion of the petitioner entered at any time after the expiration of 30 days from the rendition of that judgment of confirmation upon a showing by petitioner that no contract was let or entered into for the making of the specified improvement within the time fixed by law for the letting of the contract, or that the making of the improvement under the original proceeding was never commenced, or that the making of the improvement under the prior proceeding was never commenced, or that the making of the improvement under the prior proceedings was abandoned by petitioner. No judgment entered in such a proceeding so dismissed and vacated shall be a bar to another like or different improvement. However, after the contract for the work has been entered into, or the improvement bonds have been issued, no judgment shall be vacated or modified or any petitioner dismissed after the expiration of 30 days from the rendition of the judgment, nor shall the collection of the assessment be in any way stayed or delayed by the Committee, or any officer of the county without the consent of the contractor or bondholder.
(55 ILCS 5/5‑32001)(from Ch. 34, par. 5‑32001) Sec. 5‑32001. Right to make local improvements. Any county may make a local improvement outside of a municipality, as defined in Section 1‑1‑2 of the "Illinois Municipal Code", whenever the public necessity requires such improvement, subject only to the limitations prescribed in this Division. This Division shall not be construed as repealing any other laws with respect to county government, but shall be considered as an additional grant of power for the purposes herein set out. Any number of streets, avenues, lanes or alleys, sidewalks, or any other public places, or parts thereof, or private roads or streets, in platted subdivisions of the county to be improved may be included in one proceeding, as provided in this Division, even though they may be intersected by previously improved streets, avenues, roads or alleys which are not included in the proceeding, where they are contiguous or part of a connected system with reciprocal benefits. This Division shall not be construed to limit the powers of municipalities contained in Article 11 of the Illinois Municipal Code. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32002)(from Ch. 34, par. 5‑32002) Sec. 5‑32002. Definitions. In this Division the following terms have the meanings ascribed to them unless the context indicates otherwise: "Local improvements" means the constructing, installing, improving or extending of storm sewers, sanitary sewers or water mains; the improving, widening, extending or repairing of any street, highway, road, boulevard, alley, sidewalk or other public way; the constructing, installing or repairing of curbs, gutters, street lights and all necessary appurtenances thereto; or any combination thereof, within or abutting on any platted subdivision either prior to or after any structures are placed within such platted subdivision. "Platted subdivision" is any described tract of land which has been divided into 2 or more lots or parcels which involved the creation of a new street and which has been recorded. "County" means any county in this State which is not a home rule unit. "Attorney" means the attorney employed by the county committee of local improvements to furnish the necessary legal services in connection with any local improvement to be constructed under this Division. "Engineer" means the engineer employed by the county committee of local improvements to prepare the necessary plans, estimates and specifications, and supervise construction of any local improvement to be constructed under this Division. "Committee" means the Committee of Local Improvements created by this Division. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32003)(from Ch. 34, par. 5‑32003) Sec. 5‑32003. Committee of local improvements. There is created the Committee of Local Improvements consisting of the presiding officer of the County Board, or some person designated by him as his representative for the purposes of this Committee, the county engineer or superintendent of highways or administrative head of the county department of public works as determined by such presiding officer, and 3 members of the County Board appointed by the presiding officer of the county board with the advice and consent of the county board. The Committee shall elect from its members a president, except that the Chairman or President of the County Board, or his representative, as the case may be is prohibited from serving in that capacity. The county board shall provide by resolution for compensation not to exceed $15 per day for each member while performing his duties as a member of the Committee. The Committee may employ a secretary who shall keep the minutes of the Committee's proceedings and be the custodian of all papers pertaining to the business of the Committee and shall perform all other duties the Committee prescribes. (Source: P.A. 86‑962; 87‑217.)
(55 ILCS 5/5‑32004)(from Ch. 34, par. 5‑32004) Sec. 5‑32004. Origination of local improvements. The Committee may originate a local improvement as defined in this Division anywhere in the county outside of a municipality, as defined in Section 1‑1‑2 of the "Illinois Municipal Code", as amended, such improvement to be paid for by special assessment, either with or without a petition, by the adoption of a resolution describing the local improvement abutting or within the platted subdivision to be so improved. This resolution shall be at once transcribed into the records of the Committee and shall be presented to the members of the county board at any regularly scheduled meeting accompanied by a recommendation from the Committee for the adoption of a resolution by the county board describing the public way to be so improved. A resolution adopted without a petition shall be revoked by the county board without further action on the improvement sought if the owners of record of more than one‑half of the property abutting on or within any platted subdivision located outside the boundaries of a municipality object, by petition, by individual objections in writing, or by a combination of petitions and individual objections. Objections and petitions against an improvement shall be filed within 30 days of notification to the owners of record of the assessment. Proceedings to make a local improvement also may be instituted whenever the owners of record of one‑half the property abutting on or within any platted subdivision located outside the boundaries of a municipality, petitions the Committee of the county for a local improvement thereon. The Committee shall present such petition to the members of the county board at a regularly scheduled meeting, and recommend the adoption of a resolution by the board describing the public way to be so improved. If the resolution is so adopted by the county board, the Committee of local improvements shall proceed with all of the necessary steps for the improvement. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32005)(from Ch. 34, par. 5‑32005) Sec. 5‑32005. Applicability of Division. The provisions of this Division may be made applicable to improvement of a private street or road upon petition signed by 3/5 of the owners of record of properties abutting or served by such private street or roadway. The petition shall be filed with the Committee and is subject to the provisions of Section 5‑32004 and subsequent provisions of the Division. Upon completion of the improvement, the improvement is to be incorporated into the township or district road system as provided in Section 6‑325 of the Illinois Highway Code. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32006)(from Ch. 34, par. 5‑32006) Sec. 5‑32006. Public hearing on resolution. After the adoption of the resolution for a local improvement as provided for in this Division, the Committee by a resolution shall fix a day and hour for a public hearing thereon. The hearing shall be not less than 10 days after the adoption of the resolution. The Committee shall also have an estimate of the cost of the improvement made in writing and signed by the president. This estimate shall be itemized to the satisfaction of the Committee and shall be made a part of the records of the resolution. Notice of the time, place and hour of the proposed hearing shall be sent by mail directed to all persons who paid the general taxes for the last preceding year on each lot, block, tract or parcel of land fronting on the proposed improvement and to all municipalities the boundaries of which lie within one and one‑half miles from the location of the proposed local improvement not less than 5 days prior to the time set for the public hearing. These notices shall contain 1. The substance of the resolution adopted by the Committee; 2. The estimate of the cost of the proposed improvement; 3. A notification that the nature, extent, kind, character and the estimated cost of the proposed improvement may be changed by the Committee at the public hearing thereon. If, upon the hearing the Committee considers the proposed improvement desirable it shall adopt a resolution and prepare and submit an ordinance therefor. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32007)(from Ch. 34, par. 5‑32007) Sec. 5‑32007. Conduct of public hearing. At the time and place fixed in the specified notice for the public hearing, the Committee shall meet and hear the representations of any person desiring to be heard on the subject of the necessity for the proposed improvement, the nature thereof, or the cost as estimated. In case any person appears to object to the proposed improvement or any of the elements thereof at the public hearing the Committee shall adopt a new resolution abandoning the proposed improvement or adhering thereto or changing, altering or modifying the extent, nature, kind, character and estimated cost provided the change does not increase the estimated cost of the improvement to exceed 20% of such cost without a further public hearing thereon as it considers most desirable. Thereupon, if the proposed improvement is not abandoned, the Committee shall have an ordinance prepared to be submitted to the county board at a regularly scheduled meeting. This ordinance shall prescribe the nature, character, locality and description of the improvement and shall provide that the improvement shall be made wholly by special assessment of contiguous abutting property. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32008)(from Ch. 34, par. 5‑32008) Sec. 5‑32008. Recommendation of improvement. Accompanying any ordinance for a local improvement presented by the Committee shall be a recommendation of such improvement by the Committee signed by at least a majority of the members thereof. The recommendation by the Committee shall be prima facie evidence that all of the requirements of the law have been complied with. If a variance is shown in the proceedings in the Court it shall not affect the validity of the proceedings unless the court considers the variance willful or substantial. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32009)(from Ch. 34, par. 5‑32009) Sec. 5‑32009. Estimate of cost of improvement. An estimate of the cost of the improvement including the cost of engineering services as originally contemplated or as changed, altered, or modified at the public hearing itemized so far as the Committee thinks necessary shall be presented along with the ordinance and the recommendation. This estimate of cost shall be presented over the signature of the President of the Committee, who shall certify that, in his opinion, the estimate of cost does not exceed the probable cost of the improvement proposed and lawful expenses attending the improvement. The recommendation by the Committee shall be prima facie evidence that it is based upon full compliance with the requirements of the Division. No ordinance for any local improvement to be paid for by special assessment shall be considered or passed as provided for herein unless the ordinance is first recommended by the Committee. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32010)(from Ch. 34, par. 5‑32010) Sec. 5‑32010. Petition for levy of special assessment. Upon the passage of any ordinance for a local improvement pursuant thereto, a petition shall be filed in the circuit court in the county where the affected territory lies praying that steps be taken to levy a special assessment for the improvement in accordance with the provisions of that ordinance. There shall be attached to or filed with this petition a certified copy of the ordinance and a copy of the recommendation of the Committee and the estimate of cost as approved. The failure to file any or either of these copies shall not affect the jurisdiction of the court to proceed in the cause and to act upon the petition, but if it appears in any such cause that the copies have not been attached to or filed with the petition, before the filing of the assessment roll therein, then upon motion of any objector for that purpose on or before appearance day in the cause the entire petition and the proceedings shall be dismissed. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32011)(from Ch. 34, par. 5‑32011) Sec. 5‑32011. Manner of assessment. Upon the filing of such a petition the President of the Committee shall appoint some competent person who is a resident and elector of the county to make a true and impartial assessment of, the cost of the specified improvement upon the property benefited by the improvement. The levying officer shall apportion and assess the amount found to be of benefit to the property contiguous or abutting upon the improvement upon the several lots, blocks, tracts and parcels of land in the proportion in which they will severally be benefited by the improvement. No lot, block, tract or parcel of land shall be assessed a greater amount than it will actually be benefited. In levying any special assessment each lot, block, tract or parcel of land shall be assessed separately in the same manner as upon the assessment for general taxation. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32012)(from Ch. 34, par. 5‑32012) Sec. 5‑32012. Assessment roll. The assessment and the amount as found by the levying officer shall be known as the assessment roll. It shall contain, 1. A list of all of the lots, blocks, tracts and parcels of land assessed for the proposed improvement; 2. The amount assessed against each; 3. The name of the person who paid the taxes on each such parcel during the last preceding calendar year, in which taxes were paid as ascertained upon investigation by the levying officer making the return or under his direction; 4. The residence of the person so paying the taxes on each such parcel if the residence on diligent inquiry can be found; 5. The amount of each installment shall also be stated. The levying officer making the roll shall certify under oath that he believes that the amount assessed against each parcel of property is just and equitable and does not exceed the benefit which in each case will be derived from the improvement, and that no lot, block, tract or parcel of land has been assessed more than its proportionate share of the cost of the improvement. Each lot or part of land owned and improved as one parcel may be assessed as one parcel. Notice shall be given by the levying officer of the nature of the improvement, of the pendency of the proceedings, of the time and place of the filing of the petition therefor, of the time and place of the filing of the assessment roll and of the time and place at which application will be made for the confirmation of assessment, the same to be not less than 15 days after the mailing of such notices. Notices shall be sent by mail postage prepaid to each of the specified persons paying taxes on the respective parcels during the last preceding year during which taxes were paid at his residence as shown on the Assessment Roll. The notice shall include the legal description of the property assessed, the amount assessed to the person to whom it is directed for the improvement proposed and the total amount of the improvement. An affidavit shall be filed before the final hearing showing a compliance by the levying officer with the requirements of this Division, and also showing that the levying officer or some one acting under his direction made a careful examination of the collector's books, showing the payment of general taxes during the last preceding year in which the taxes were paid thereon, to ascertain the person who last paid the taxes on the respective parcel and a diligent search for his residence and that the report clearly states the person and residence as ascertained by the affiant. This report and affidavit shall be sufficient evidence for the purpose of this proceeding of the correctness of the assessment roll in these particulars. In case the affidavit is found in any respect willfully false, the person making it is guilty of perjury. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32013)(from Ch. 34, par. 5‑32013) Sec. 5‑32013. Installments; interest. The ordinance provided for in this Division shall provide that the aggregate amounts assessed in each individual assessment shall be divided into installments not more than 10 in number. Such division shall be made so that all installments shall be equal in amount except that all fractional amounts shall be added to the first installment so as to leave the remaining of the aggregate equal in amount and each a multiple of $100. The first installment shall be due and payable on January 2 next, after the date of the first voucher issued on account of construction work done, and the second installment one year thereafter and so on annually until all installments are paid. The Committee shall file in the office of the Clerk of the Circuit Court in which such assessment was confirmed a certificate signed by its secretary of the date of the first voucher and the amount thereof within 30 days after the issuance thereof. All installments shall bear interest as hereinafter provided until paid at the rate of not to exceed 7% annually. Interest on assessments shall begin to run from the date of the first voucher issued on account of construction work done. The interest on each installment shall be paid as follows: On January 2, next succeeding the date of the first voucher as certified the interest accruing up to that time on all unpaid installments shall be due and payable with the installment, and thereafter the interest on all unpaid installments then payable shall be payable annually and be collected therewith. In all cases the County Collector, whenever payment is made on any installment, shall collect interest thereon up to the date of such payment whether the payment be made at or after maturity. Any person may at any time pay the whole assessment against any lot, piece or parcel of land or any installment thereof with interest as herein provided up to the date of the payment. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32014)(from Ch. 34, par. 5‑32014) Sec. 5‑32014. Special assessment notice. The Committee in addition to the notice in this Division provided for shall publish a notice at least twice not more than 30 days nor less than 15 days in advance of the time at which the confirmation of the specified assessment is to be sought, in one or more newspapers published in the county or if no newspaper is published therein then in one or more newspapers with a general circulation in the county. The notice shall be over the name of the levying officer and shall be substantially as follows:
"SPECIAL ASSESSMENT NOTICE
Notice is hereby given to all persons interested that the County of .... has order that (herein insert a brief description of the nature of the improvement), the ordinance for the improvement being on file in the office of the County Clerk, having applied to the Circuit Court of .... County, for an assessment of the costs of the improvement according to benefits an assessment therefor having been made and returned to that Court, a final hearing thereon will be had on (insert date), or as soon thereafter as the business of the Court will permit. All persons desiring may file objections in that Court before that day and may appear on the hearing and make their defense. (Here give date)NAME.... (LEVYING OFFICER)."The number of installments and the rate of interest also shall be stated. (Source: P.A. 91‑357, eff. 7‑29‑99.)
(55 ILCS 5/5‑32015)(from Ch. 34, par. 5‑32015) Sec. 5‑32015. Extension of time for filing objections. If 15 days have not elapsed between the first publication and the day fixed in the notice for filing objections, the cause shall be continued for 15 days, and time for filing objections shall be correspondingly extended. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32016)(from Ch. 34, par. 5‑32016) Sec. 5‑32016. Filing objections to report; default. Any person interested in any real estate to be affected by an assessment, may appear and file objections to the report by the time mentioned in the specified notice, or in case of incomplete notice than as specified in Section 5‑32015, or within such further time as the court may allow. The court may make an order in regard to the time of filing these objections but no prior rule need be taken therefor unless directed by the court. As to all lots, blocks, tracts and parcels of land, to the assessment of which objections are not filed within the specified time, or such other time as may be ordered by the court, default may be entered and the assessment may be confirmed by the court, notwithstanding the fact that objections may be pending and undisposed of as to other property. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32017)(from Ch. 34, par. 5‑32017) Sec. 5‑32017. Inquiries; powers of court. Upon objections or motions for that purpose, the court in which the specified proceeding is pending may inquire in a summary way whether the officer making roll has omitted any property benefited, and whether or not the assessment as made and returned is an equitable and just distribution of the cost of the improvement among the parcels of property assessed. The court has the power upon such application being made, to revise and correct the assessment levied or to change the manner of distribution among the parcels of private property, so as to produce a just and equitable assessment. The court may either make such corrections or change or determine in general the manner in which the corrections or changes shall be made and refer the assessment roll back to the levying officer for revisions, corrections or alterations in such manner as the court may determine. (Source: P.A. 91‑357, eff. 7‑29‑99.)
(55 ILCS 5/5‑32018)(from Ch. 34, par. 5‑32018) Sec. 5‑32018. Hearing. On the application of the petitioner, at any time after the return day, the court may set down all objections, except the objection that the property of the objector will not be benefited to the amount assessed against it, and that it is assessed more than its proportionate share of the cost of the improvement, for a hearing at a time to be fixed by the court. Upon this hearing the court shall determine all questions relating to the sufficiency of the proceedings and of the benefits between the different parcels of property assessed, together with all other questions arising in that proceeding, with the exception specified, and shall thereupon enter an order in accordance with the conclusions it reaches. But this order shall not be a final disposition of any of these questions for the purpose of appeal, unless the objectors waive further controversy as to the remaining question upon the record. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32019)(from Ch. 34, par. 5‑32019) Sec. 5‑32019. Proceedings. If it is objected to on the part of any property assessed for such an improvement, that it will not be benefited thereby to the amount assessed thereon, and that it is assessed more than its proportionate share of the cost of the improvement, and a jury is not waived by agreement of the parties, the court shall impanel a jury to try that issue. In that case unless otherwise ordered by the court, all such objections shall be tried and disposed of before a single jury. The assessment roll, as returned by the officer who made it, or as revised and corrected by the court on the hearing of the legal objections, shall be prima facie evidence of the correctness of the amount assessed against each objected owner but shall not be counted as the testimony of any witness or witnesses in the cause. That assessment roll may be submitted to the jury and may be taken into the jury room by the jury when it retires to deliberate on its verdict. Either party may introduce such other evidence as may bear upon that issue or issues. The hearing shall be conducted as in other civil cases. If it appears that the property of any objector is assessed more than it will be benefited by the specified improvement, or more than its proportionate share of the cost of the improvement, the jury shall so find, and it shall also find the amount for which that property ought to be assessed, and judgment shall be rendered accordingly. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32020)(from Ch. 34, par. 5‑32020) Sec. 5‑32020. Distribution of deficiency. Whenever, on a hearing by the court or before a jury, the amount of any assessment is reduced or cancelled, so that there is a deficiency in the total amount remaining assessed in the proceeding, the court may, in the same proceeding, distribute this deficiency upon the other property in the district assessed, in such manner as the court finds just and equitable, not exceeding, however, the amount such property will be benefited by the specified improvement. In case any portion of this deficiency is charged against such property not represented in court, a new notice, of the same nature as the original notice, shall be given in like manner as the original notice, to show the cause why the assessment, as thus increased, should not be confirmed. The owners of or parties interested in such property have the right to object in the same form and with the same effect as in case of the original assessment, and the court has the same power to dispose thereof. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32021)(from Ch. 34, par. 5‑32021) Sec. 5‑32021. Time for hearing. The hearing in all the cases arising under this Division, may be had at such time as the court may designate, and such proceedings shall have precedence over all other cases in any court, where they are brought, except criminal cases, or other cases in which the public is a moving party. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32022)(from Ch. 34, par. 5‑32022) Sec. 5‑32022. Additional powers of court. The court before which any such proceedings may be pending may modify, alter, change, annul, or confirm any assessment returned as specified, in addition to the authority already conferred upon it, and may take all such proceedings, and make all such orders, as may be necessary to the improvement, according to the principles of this Division, and may from time to time, as may be necessary, continue the application for that purpose as to the whole or any part of the premises. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32023)(from Ch. 34, par. 5‑32023) Sec. 5‑32023. Effect of similar improvements previously made in same locality. It is no objection to the legality of any local improvement that a similar improvement has been previously made in the same locality, if the ordinance therefor is recommended by the Committee as above provided, but nothing contained in this Division shall interfere with any defense in this proceeding relating to the benefits received therefrom. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32024)(from Ch. 34, par. 5‑32024) Sec. 5‑32024. Confirmation of assessment roll. In case of a special assessment to be paid by installments under the provisions of this Division, the order of confirmation that is entered upon the return of the assessment roll shall apply to all of the installments thereof, and may be entered in one order. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32025)(from Ch. 34, par. 5‑32025) Sec. 5‑32025. Review; effect of judgments. The judgments of the court shall be final as to all the issues involved, and the proceedings in the specified cause shall be subject to review by appeal as provided in this Division and not otherwise. However, by mutual consent such a judgment may be vacated or modified notwithstanding the expiration of 30 days from the rendition of the judgment, except as provided in this Division. Such judgment shall have the effect of several judgments as to each tract or parcel of land assessed, and no appeal from any such judgment shall invalidate or delay the judgments, except as to the property concerning which the appeal is taken. Such judgment shall be a lien on behalf of the county making any improvement, for the payment of which the special assessment is levied, on the property assessed from the date thereof, to the same extent and of equal force and validity as a lien for the general taxes until the judgment is paid or the property against which any such judgment is entered is sold to pay the judgment. Nothing in this Division shall interfere with the right of the petitioner to dismiss its proceedings, and for that purpose to vacate such a judgment at its election at any time before commencing the actual collection of the assessment. The court in which the judgment is rendered shall enter an order vacating or annulling the judgment of confirmation on motion of the petitioner entered at any time after the expiration of 30 days from the rendition of that judgment of confirmation upon a showing by petitioner that no contract was let or entered into for the making of the specified improvement within the time fixed by law for the letting of the contract, or that the making of the improvement under the original proceeding was never commenced, or that the making of the improvement under the prior proceeding was never commenced, or that the making of the improvement under the prior proceedings was abandoned by petitioner. No judgment entered in such a proceeding so dismissed and vacated shall be a bar to another like or different improvement. However, after the contract for the work has been entered into, or the improvement bonds have been issued, no judgment shall be vacated or modified or any petitioner dismissed after the expiration of 30 days from the rendition of the judgment, nor shall the collection of the assessment be in any way stayed or delayed by the Committee, or any officer of the county without the consent of the contractor or bondholder.
(55 ILCS 5/5‑32001)(from Ch. 34, par. 5‑32001) Sec. 5‑32001. Right to make local improvements. Any county may make a local improvement outside of a municipality, as defined in Section 1‑1‑2 of the "Illinois Municipal Code", whenever the public necessity requires such improvement, subject only to the limitations prescribed in this Division. This Division shall not be construed as repealing any other laws with respect to county government, but shall be considered as an additional grant of power for the purposes herein set out. Any number of streets, avenues, lanes or alleys, sidewalks, or any other public places, or parts thereof, or private roads or streets, in platted subdivisions of the county to be improved may be included in one proceeding, as provided in this Division, even though they may be intersected by previously improved streets, avenues, roads or alleys which are not included in the proceeding, where they are contiguous or part of a connected system with reciprocal benefits. This Division shall not be construed to limit the powers of municipalities contained in Article 11 of the Illinois Municipal Code. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32002)(from Ch. 34, par. 5‑32002) Sec. 5‑32002. Definitions. In this Division the following terms have the meanings ascribed to them unless the context indicates otherwise: "Local improvements" means the constructing, installing, improving or extending of storm sewers, sanitary sewers or water mains; the improving, widening, extending or repairing of any street, highway, road, boulevard, alley, sidewalk or other public way; the constructing, installing or repairing of curbs, gutters, street lights and all necessary appurtenances thereto; or any combination thereof, within or abutting on any platted subdivision either prior to or after any structures are placed within such platted subdivision. "Platted subdivision" is any described tract of land which has been divided into 2 or more lots or parcels which involved the creation of a new street and which has been recorded. "County" means any county in this State which is not a home rule unit. "Attorney" means the attorney employed by the county committee of local improvements to furnish the necessary legal services in connection with any local improvement to be constructed under this Division. "Engineer" means the engineer employed by the county committee of local improvements to prepare the necessary plans, estimates and specifications, and supervise construction of any local improvement to be constructed under this Division. "Committee" means the Committee of Local Improvements created by this Division. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32003)(from Ch. 34, par. 5‑32003) Sec. 5‑32003. Committee of local improvements. There is created the Committee of Local Improvements consisting of the presiding officer of the County Board, or some person designated by him as his representative for the purposes of this Committee, the county engineer or superintendent of highways or administrative head of the county department of public works as determined by such presiding officer, and 3 members of the County Board appointed by the presiding officer of the county board with the advice and consent of the county board. The Committee shall elect from its members a president, except that the Chairman or President of the County Board, or his representative, as the case may be is prohibited from serving in that capacity. The county board shall provide by resolution for compensation not to exceed $15 per day for each member while performing his duties as a member of the Committee. The Committee may employ a secretary who shall keep the minutes of the Committee's proceedings and be the custodian of all papers pertaining to the business of the Committee and shall perform all other duties the Committee prescribes. (Source: P.A. 86‑962; 87‑217.)
(55 ILCS 5/5‑32004)(from Ch. 34, par. 5‑32004) Sec. 5‑32004. Origination of local improvements. The Committee may originate a local improvement as defined in this Division anywhere in the county outside of a municipality, as defined in Section 1‑1‑2 of the "Illinois Municipal Code", as amended, such improvement to be paid for by special assessment, either with or without a petition, by the adoption of a resolution describing the local improvement abutting or within the platted subdivision to be so improved. This resolution shall be at once transcribed into the records of the Committee and shall be presented to the members of the county board at any regularly scheduled meeting accompanied by a recommendation from the Committee for the adoption of a resolution by the county board describing the public way to be so improved. A resolution adopted without a petition shall be revoked by the county board without further action on the improvement sought if the owners of record of more than one‑half of the property abutting on or within any platted subdivision located outside the boundaries of a municipality object, by petition, by individual objections in writing, or by a combination of petitions and individual objections. Objections and petitions against an improvement shall be filed within 30 days of notification to the owners of record of the assessment. Proceedings to make a local improvement also may be instituted whenever the owners of record of one‑half the property abutting on or within any platted subdivision located outside the boundaries of a municipality, petitions the Committee of the county for a local improvement thereon. The Committee shall present such petition to the members of the county board at a regularly scheduled meeting, and recommend the adoption of a resolution by the board describing the public way to be so improved. If the resolution is so adopted by the county board, the Committee of local improvements shall proceed with all of the necessary steps for the improvement. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32005)(from Ch. 34, par. 5‑32005) Sec. 5‑32005. Applicability of Division. The provisions of this Division may be made applicable to improvement of a private street or road upon petition signed by 3/5 of the owners of record of properties abutting or served by such private street or roadway. The petition shall be filed with the Committee and is subject to the provisions of Section 5‑32004 and subsequent provisions of the Division. Upon completion of the improvement, the improvement is to be incorporated into the township or district road system as provided in Section 6‑325 of the Illinois Highway Code. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32006)(from Ch. 34, par. 5‑32006) Sec. 5‑32006. Public hearing on resolution. After the adoption of the resolution for a local improvement as provided for in this Division, the Committee by a resolution shall fix a day and hour for a public hearing thereon. The hearing shall be not less than 10 days after the adoption of the resolution. The Committee shall also have an estimate of the cost of the improvement made in writing and signed by the president. This estimate shall be itemized to the satisfaction of the Committee and shall be made a part of the records of the resolution. Notice of the time, place and hour of the proposed hearing shall be sent by mail directed to all persons who paid the general taxes for the last preceding year on each lot, block, tract or parcel of land fronting on the proposed improvement and to all municipalities the boundaries of which lie within one and one‑half miles from the location of the proposed local improvement not less than 5 days prior to the time set for the public hearing. These notices shall contain 1. The substance of the resolution adopted by the Committee; 2. The estimate of the cost of the proposed improvement; 3. A notification that the nature, extent, kind, character and the estimated cost of the proposed improvement may be changed by the Committee at the public hearing thereon. If, upon the hearing the Committee considers the proposed improvement desirable it shall adopt a resolution and prepare and submit an ordinance therefor. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32007)(from Ch. 34, par. 5‑32007) Sec. 5‑32007. Conduct of public hearing. At the time and place fixed in the specified notice for the public hearing, the Committee shall meet and hear the representations of any person desiring to be heard on the subject of the necessity for the proposed improvement, the nature thereof, or the cost as estimated. In case any person appears to object to the proposed improvement or any of the elements thereof at the public hearing the Committee shall adopt a new resolution abandoning the proposed improvement or adhering thereto or changing, altering or modifying the extent, nature, kind, character and estimated cost provided the change does not increase the estimated cost of the improvement to exceed 20% of such cost without a further public hearing thereon as it considers most desirable. Thereupon, if the proposed improvement is not abandoned, the Committee shall have an ordinance prepared to be submitted to the county board at a regularly scheduled meeting. This ordinance shall prescribe the nature, character, locality and description of the improvement and shall provide that the improvement shall be made wholly by special assessment of contiguous abutting property. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32008)(from Ch. 34, par. 5‑32008) Sec. 5‑32008. Recommendation of improvement. Accompanying any ordinance for a local improvement presented by the Committee shall be a recommendation of such improvement by the Committee signed by at least a majority of the members thereof. The recommendation by the Committee shall be prima facie evidence that all of the requirements of the law have been complied with. If a variance is shown in the proceedings in the Court it shall not affect the validity of the proceedings unless the court considers the variance willful or substantial. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32009)(from Ch. 34, par. 5‑32009) Sec. 5‑32009. Estimate of cost of improvement. An estimate of the cost of the improvement including the cost of engineering services as originally contemplated or as changed, altered, or modified at the public hearing itemized so far as the Committee thinks necessary shall be presented along with the ordinance and the recommendation. This estimate of cost shall be presented over the signature of the President of the Committee, who shall certify that, in his opinion, the estimate of cost does not exceed the probable cost of the improvement proposed and lawful expenses attending the improvement. The recommendation by the Committee shall be prima facie evidence that it is based upon full compliance with the requirements of the Division. No ordinance for any local improvement to be paid for by special assessment shall be considered or passed as provided for herein unless the ordinance is first recommended by the Committee. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32010)(from Ch. 34, par. 5‑32010) Sec. 5‑32010. Petition for levy of special assessment. Upon the passage of any ordinance for a local improvement pursuant thereto, a petition shall be filed in the circuit court in the county where the affected territory lies praying that steps be taken to levy a special assessment for the improvement in accordance with the provisions of that ordinance. There shall be attached to or filed with this petition a certified copy of the ordinance and a copy of the recommendation of the Committee and the estimate of cost as approved. The failure to file any or either of these copies shall not affect the jurisdiction of the court to proceed in the cause and to act upon the petition, but if it appears in any such cause that the copies have not been attached to or filed with the petition, before the filing of the assessment roll therein, then upon motion of any objector for that purpose on or before appearance day in the cause the entire petition and the proceedings shall be dismissed. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32011)(from Ch. 34, par. 5‑32011) Sec. 5‑32011. Manner of assessment. Upon the filing of such a petition the President of the Committee shall appoint some competent person who is a resident and elector of the county to make a true and impartial assessment of, the cost of the specified improvement upon the property benefited by the improvement. The levying officer shall apportion and assess the amount found to be of benefit to the property contiguous or abutting upon the improvement upon the several lots, blocks, tracts and parcels of land in the proportion in which they will severally be benefited by the improvement. No lot, block, tract or parcel of land shall be assessed a greater amount than it will actually be benefited. In levying any special assessment each lot, block, tract or parcel of land shall be assessed separately in the same manner as upon the assessment for general taxation. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32012)(from Ch. 34, par. 5‑32012) Sec. 5‑32012. Assessment roll. The assessment and the amount as found by the levying officer shall be known as the assessment roll. It shall contain, 1. A list of all of the lots, blocks, tracts and parcels of land assessed for the proposed improvement; 2. The amount assessed against each; 3. The name of the person who paid the taxes on each such parcel during the last preceding calendar year, in which taxes were paid as ascertained upon investigation by the levying officer making the return or under his direction; 4. The residence of the person so paying the taxes on each such parcel if the residence on diligent inquiry can be found; 5. The amount of each installment shall also be stated. The levying officer making the roll shall certify under oath that he believes that the amount assessed against each parcel of property is just and equitable and does not exceed the benefit which in each case will be derived from the improvement, and that no lot, block, tract or parcel of land has been assessed more than its proportionate share of the cost of the improvement. Each lot or part of land owned and improved as one parcel may be assessed as one parcel. Notice shall be given by the levying officer of the nature of the improvement, of the pendency of the proceedings, of the time and place of the filing of the petition therefor, of the time and place of the filing of the assessment roll and of the time and place at which application will be made for the confirmation of assessment, the same to be not less than 15 days after the mailing of such notices. Notices shall be sent by mail postage prepaid to each of the specified persons paying taxes on the respective parcels during the last preceding year during which taxes were paid at his residence as shown on the Assessment Roll. The notice shall include the legal description of the property assessed, the amount assessed to the person to whom it is directed for the improvement proposed and the total amount of the improvement. An affidavit shall be filed before the final hearing showing a compliance by the levying officer with the requirements of this Division, and also showing that the levying officer or some one acting under his direction made a careful examination of the collector's books, showing the payment of general taxes during the last preceding year in which the taxes were paid thereon, to ascertain the person who last paid the taxes on the respective parcel and a diligent search for his residence and that the report clearly states the person and residence as ascertained by the affiant. This report and affidavit shall be sufficient evidence for the purpose of this proceeding of the correctness of the assessment roll in these particulars. In case the affidavit is found in any respect willfully false, the person making it is guilty of perjury. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32013)(from Ch. 34, par. 5‑32013) Sec. 5‑32013. Installments; interest. The ordinance provided for in this Division shall provide that the aggregate amounts assessed in each individual assessment shall be divided into installments not more than 10 in number. Such division shall be made so that all installments shall be equal in amount except that all fractional amounts shall be added to the first installment so as to leave the remaining of the aggregate equal in amount and each a multiple of $100. The first installment shall be due and payable on January 2 next, after the date of the first voucher issued on account of construction work done, and the second installment one year thereafter and so on annually until all installments are paid. The Committee shall file in the office of the Clerk of the Circuit Court in which such assessment was confirmed a certificate signed by its secretary of the date of the first voucher and the amount thereof within 30 days after the issuance thereof. All installments shall bear interest as hereinafter provided until paid at the rate of not to exceed 7% annually. Interest on assessments shall begin to run from the date of the first voucher issued on account of construction work done. The interest on each installment shall be paid as follows: On January 2, next succeeding the date of the first voucher as certified the interest accruing up to that time on all unpaid installments shall be due and payable with the installment, and thereafter the interest on all unpaid installments then payable shall be payable annually and be collected therewith. In all cases the County Collector, whenever payment is made on any installment, shall collect interest thereon up to the date of such payment whether the payment be made at or after maturity. Any person may at any time pay the whole assessment against any lot, piece or parcel of land or any installment thereof with interest as herein provided up to the date of the payment. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32014)(from Ch. 34, par. 5‑32014) Sec. 5‑32014. Special assessment notice. The Committee in addition to the notice in this Division provided for shall publish a notice at least twice not more than 30 days nor less than 15 days in advance of the time at which the confirmation of the specified assessment is to be sought, in one or more newspapers published in the county or if no newspaper is published therein then in one or more newspapers with a general circulation in the county. The notice shall be over the name of the levying officer and shall be substantially as follows:
"SPECIAL ASSESSMENT NOTICE
Notice is hereby given to all persons interested that the County of .... has order that (herein insert a brief description of the nature of the improvement), the ordinance for the improvement being on file in the office of the County Clerk, having applied to the Circuit Court of .... County, for an assessment of the costs of the improvement according to benefits an assessment therefor having been made and returned to that Court, a final hearing thereon will be had on (insert date), or as soon thereafter as the business of the Court will permit. All persons desiring may file objections in that Court before that day and may appear on the hearing and make their defense. (Here give date)NAME.... (LEVYING OFFICER)."The number of installments and the rate of interest also shall be stated. (Source: P.A. 91‑357, eff. 7‑29‑99.)
(55 ILCS 5/5‑32015)(from Ch. 34, par. 5‑32015) Sec. 5‑32015. Extension of time for filing objections. If 15 days have not elapsed between the first publication and the day fixed in the notice for filing objections, the cause shall be continued for 15 days, and time for filing objections shall be correspondingly extended. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32016)(from Ch. 34, par. 5‑32016) Sec. 5‑32016. Filing objections to report; default. Any person interested in any real estate to be affected by an assessment, may appear and file objections to the report by the time mentioned in the specified notice, or in case of incomplete notice than as specified in Section 5‑32015, or within such further time as the court may allow. The court may make an order in regard to the time of filing these objections but no prior rule need be taken therefor unless directed by the court. As to all lots, blocks, tracts and parcels of land, to the assessment of which objections are not filed within the specified time, or such other time as may be ordered by the court, default may be entered and the assessment may be confirmed by the court, notwithstanding the fact that objections may be pending and undisposed of as to other property. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32017)(from Ch. 34, par. 5‑32017) Sec. 5‑32017. Inquiries; powers of court. Upon objections or motions for that purpose, the court in which the specified proceeding is pending may inquire in a summary way whether the officer making roll has omitted any property benefited, and whether or not the assessment as made and returned is an equitable and just distribution of the cost of the improvement among the parcels of property assessed. The court has the power upon such application being made, to revise and correct the assessment levied or to change the manner of distribution among the parcels of private property, so as to produce a just and equitable assessment. The court may either make such corrections or change or determine in general the manner in which the corrections or changes shall be made and refer the assessment roll back to the levying officer for revisions, corrections or alterations in such manner as the court may determine. (Source: P.A. 91‑357, eff. 7‑29‑99.)
(55 ILCS 5/5‑32018)(from Ch. 34, par. 5‑32018) Sec. 5‑32018. Hearing. On the application of the petitioner, at any time after the return day, the court may set down all objections, except the objection that the property of the objector will not be benefited to the amount assessed against it, and that it is assessed more than its proportionate share of the cost of the improvement, for a hearing at a time to be fixed by the court. Upon this hearing the court shall determine all questions relating to the sufficiency of the proceedings and of the benefits between the different parcels of property assessed, together with all other questions arising in that proceeding, with the exception specified, and shall thereupon enter an order in accordance with the conclusions it reaches. But this order shall not be a final disposition of any of these questions for the purpose of appeal, unless the objectors waive further controversy as to the remaining question upon the record. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32019)(from Ch. 34, par. 5‑32019) Sec. 5‑32019. Proceedings. If it is objected to on the part of any property assessed for such an improvement, that it will not be benefited thereby to the amount assessed thereon, and that it is assessed more than its proportionate share of the cost of the improvement, and a jury is not waived by agreement of the parties, the court shall impanel a jury to try that issue. In that case unless otherwise ordered by the court, all such objections shall be tried and disposed of before a single jury. The assessment roll, as returned by the officer who made it, or as revised and corrected by the court on the hearing of the legal objections, shall be prima facie evidence of the correctness of the amount assessed against each objected owner but shall not be counted as the testimony of any witness or witnesses in the cause. That assessment roll may be submitted to the jury and may be taken into the jury room by the jury when it retires to deliberate on its verdict. Either party may introduce such other evidence as may bear upon that issue or issues. The hearing shall be conducted as in other civil cases. If it appears that the property of any objector is assessed more than it will be benefited by the specified improvement, or more than its proportionate share of the cost of the improvement, the jury shall so find, and it shall also find the amount for which that property ought to be assessed, and judgment shall be rendered accordingly. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32020)(from Ch. 34, par. 5‑32020) Sec. 5‑32020. Distribution of deficiency. Whenever, on a hearing by the court or before a jury, the amount of any assessment is reduced or cancelled, so that there is a deficiency in the total amount remaining assessed in the proceeding, the court may, in the same proceeding, distribute this deficiency upon the other property in the district assessed, in such manner as the court finds just and equitable, not exceeding, however, the amount such property will be benefited by the specified improvement. In case any portion of this deficiency is charged against such property not represented in court, a new notice, of the same nature as the original notice, shall be given in like manner as the original notice, to show the cause why the assessment, as thus increased, should not be confirmed. The owners of or parties interested in such property have the right to object in the same form and with the same effect as in case of the original assessment, and the court has the same power to dispose thereof. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32021)(from Ch. 34, par. 5‑32021) Sec. 5‑32021. Time for hearing. The hearing in all the cases arising under this Division, may be had at such time as the court may designate, and such proceedings shall have precedence over all other cases in any court, where they are brought, except criminal cases, or other cases in which the public is a moving party. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32022)(from Ch. 34, par. 5‑32022) Sec. 5‑32022. Additional powers of court. The court before which any such proceedings may be pending may modify, alter, change, annul, or confirm any assessment returned as specified, in addition to the authority already conferred upon it, and may take all such proceedings, and make all such orders, as may be necessary to the improvement, according to the principles of this Division, and may from time to time, as may be necessary, continue the application for that purpose as to the whole or any part of the premises. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32023)(from Ch. 34, par. 5‑32023) Sec. 5‑32023. Effect of similar improvements previously made in same locality. It is no objection to the legality of any local improvement that a similar improvement has been previously made in the same locality, if the ordinance therefor is recommended by the Committee as above provided, but nothing contained in this Division shall interfere with any defense in this proceeding relating to the benefits received therefrom. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32024)(from Ch. 34, par. 5‑32024) Sec. 5‑32024. Confirmation of assessment roll. In case of a special assessment to be paid by installments under the provisions of this Division, the order of confirmation that is entered upon the return of the assessment roll shall apply to all of the installments thereof, and may be entered in one order. (Source: P.A. 86‑962.)
(55 ILCS 5/5‑32025)(from Ch. 34, par. 5‑32025) Sec. 5‑32025. Review; effect of judgments. The judgments of the court shall be final as to all the issues involved, and the proceedings in the specified cause shall be subject to review by appeal as provided in this Division and not otherwise. However, by mutual consent such a judgment may be vacated or modified notwithstanding the expiration of 30 days from the rendition of the judgment, except as provided in this Division. Such judgment shall have the effect of several judgments as to each tract or parcel of land assessed, and no appeal from any such judgment shall invalidate or delay the judgments, except as to the property concerning which the appeal is taken. Such judgment shall be a lien on behalf of the county making any improvement, for the payment of which the special assessment is levied, on the property assessed from the date thereof, to the same extent and of equal force and validity as a lien for the general taxes until the judgment is paid or the property against which any such judgment is entered is sold to pay the judgment. Nothing in this Division shall interfere with the right of the petitioner to dismiss its proceedings, and for that purpose to vacate such a judgment at its election at any time before commencing the actual collection of the assessment. The court in which the judgment is rendered shall enter an order vacating or annulling the judgment of confirmation on motion of the petitioner entered at any time after the expiration of 30 days from the rendition of that judgment of confirmation upon a showing by petitioner that no contract was let or entered into for the making of the specified improvement within the time fixed by law for the letting of the contract, or that the making of the improvement under the original proceeding was never commenced, or that the making of the improvement under the prior proceeding was never commenced, or that the making of the improvement under the prior proceedings was abandoned by petitioner. No judgment entered in such a proceeding so dismissed and vacated shall be a bar to another like or different improvement. However, after the contract for the work has been entered into, or the improvement bonds have been issued, no judgment shall be vacated or modified or any petitioner dismissed after the expiration of 30 days from the rendition of the judgment, nor shall the collection of the assessment be in any way stayed or delayed by the Committee, or any officer of the county without the consent of the contractor or bondholder.
