State Codes and Statutes

Statutes > Illinois > Chapter770 > 2254

    (770 ILCS 60/0.01) (from Ch. 82, par. 0.01)
    Sec. 0.01. Short title. This Act may be cited as the Mechanics Lien Act.
(Source: P.A. 86‑1324.)

    (770 ILCS 60/1)(from Ch. 82, par. 1)
    Sec. 1. Contractor defined; amount of lien; waiver of lien; attachment of lien; agreement to waive; when not enforceable.
    (a) Any person who shall by any contract or contracts, express or implied, or partly expressed or implied, with the owner of a lot or tract of land, or with one whom the owner has authorized or knowingly permitted to contract, to improve the lot or tract of land or for the purpose of improving the tract of land, or to manage a structure under construction thereon, is known under this Act as a contractor and has a lien upon the whole of such lot or tract of land and upon adjoining or adjacent lots or tracts of land of such owner constituting the same premises and occupied or used in connection with such lot or tract of land as a place of residence or business; and in case the contract relates to 2 or more buildings, on 2 or more lots or tracts of land, upon all such lots and tracts of land and improvements thereon for the amount due to him or her for the material, fixtures, apparatus, machinery, services or labor, and interest at the rate of 10% per annum from the date the same is due. This lien extends to an estate in fee, for life, for years, or any other estate or any right of redemption or other interest that the owner may have in the lot or tract of land at the time of making such contract or may subsequently acquire and this lien attaches as of the date of the contract.
    (b) As used in subsection (a) of this Section, "improve" means to furnish labor, services, material, fixtures, apparatus or machinery, forms or form work in the process of construction where cement, concrete or like material is used for the purpose of or in the building, altering, repairing or ornamenting any house or other building, walk or sidewalk, whether the walk or sidewalk is on the land or bordering thereon, driveway, fence or improvement or appurtenances to the lot or tract of land or connected therewith, and upon, over or under a sidewalk, street or alley adjoining; or fill, sod or excavate such lot or tract of land, or do landscape work thereon or therefor; or raise or lower any house thereon or remove any house thereto, or remove any house or other structure therefrom, or perform any services or incur any expense as an architect, structural engineer, professional engineer, land surveyor or property manager in, for or on a lot or tract of land for any such purpose; or drill any water well thereon; or furnish or perform labor or services as superintendent, time keeper, mechanic, laborer or otherwise, in the building, altering, repairing or ornamenting of the same; or furnish material, fixtures, apparatus, machinery, labor or services, forms or form work used in the process of construction where concrete, cement or like material is used, or drill any water well on the order of his agent, architect, structural engineer or superintendent having charge of the improvements, building, altering, repairing or ornamenting the same.
    (c) The taking of additional security by the contractor or sub‑contractor is not a waiver of any right of lien which he may have by virtue of this Act, unless made a waiver by express agreement of the parties and the waiver is not prohibited by this Act.
    (d) An agreement to waive any right to enforce or claim any lien under this Act where the agreement is in anticipation of and in consideration for the awarding of a contract or subcontract, either express or implied, to perform work or supply materials for an improvement upon real property is against public policy and unenforceable. This Section does not prohibit release of lien under subsection (b) of Section 35 of this Act or prohibit subordination of the lien, except as provided in Section 21.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/1.1)
    Sec. 1.1. (Repealed).
(Source: P.A. 87‑361. Repealed by P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/1.2)
    Sec. 1.2. Rental equipment liens. In addition to persons who would otherwise have a lien under this Act, any person, whether contractor or subcontractor, who leases construction equipment to another for use in the process of constructing a specific improvement to real estate, has a lien for the rental value of the construction equipment to the same extent and in the same manner as provided in this Act for other liens. This Section shall apply only if, and to the extent that, the equipment is used on or about the site of the improvement. This Section does not apply if the improvement is either a single family residence or a multi‑family residence of fewer than 12 units in a single building.
(Source: P.A. 95‑274, eff. 8‑17‑07.)

    (770 ILCS 60/2)(from Ch. 82, par. 2)
    Sec. 2. Labor, services, material, fixtures, apparatus or machinery, forms or form work furnished by mistake. Any person furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work for the erection of a building, or structure, or improvement, by mistake upon land owned by another than the party contracting as owner, shall have a lien for such labor, services, material, fixtures, apparatus or machinery, forms or form work upon such building, or structure or improvement, and the court, in the enforcement of such lien, shall order and direct such building, structure or improvement to be separately sold under its judgment, and the purchaser may remove the same within such reasonable time as the court may fix.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/3)(from Ch. 82, par. 3)
    Sec. 3. Labor, services, material, fixtures, apparatus or machinery, forms or form work furnished for lands of married person; lands held by husband and wife. If any such labor, services, material, fixtures, apparatus or machinery, forms or form work are performed upon lands belonging to any married person, with the married person's knowledge and not against the married person's protest in writing, as provided in Section 1 of this Act, in pursuance of a contract with the spouse of such married person, the person furnishing such labor, services, material, fixtures, apparatus or machinery, forms or form work shall have a lien upon such property, the same as if such contract had been made with the married person, and in case the title to such lands upon which improvements are made is held by married persons jointly, the lien given by this Act shall attach to such lands and improvements, if the improvements be made in pursuance of a contract with both of them, or in pursuance of a contract with either of them, and in such cases no claim of homestead right set up by a husband or wife shall defeat the lien given by this Act. For purposes of this Section, property shall be deemed to be held jointly if title is held by the parties either in tenancy by the entirety or jointly, with right of survivorship and not as tenants in common.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/4) (from Ch. 82, par. 4)
    Sec. 4. When the owner of the land shall fail to pay the contractor moneys justly due him under the contract at the time when the same should be paid, or fails to perform his part of the contract in any other manner, the contractor may discontinue work, and the contractor shall not be held liable for any delay on his part during the period of, or caused by, such breach of contract on the part of the owner; and if after such breach for the period of ten days the owner shall fail to comply with his contract, the contractor may abandon the work, and in such a case the contractor shall be entitled to enforce his lien for the value of what has been done, and the court shall adjust his claim and allow him a lien accordingly. In such cases all persons furnishing material which has not been incorporated in the improvement shall have the right to take possession of and remove the same if he so elects.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/5)(from Ch. 82, par. 5)
    Sec. 5. Statement of persons furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work notice to owner of waiver; size of type.
    (a) It shall be the duty of the contractor to give the owner, and the duty of the owner to require of the contractor, before the owner or his agent, architect, or superintendent shall pay or cause to be paid to the contractor or to his order any moneys or other consideration due or to become due to the contractor, or make or cause to be made to the contractor any advancement of any moneys or any other consideration, a statement in writing, under oath or verified by affidavit, of the names and addresses of all parties furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work and of the amounts due or to become due to each. Merchants and dealers in materials only shall not be required to make statements required in this Section.
    (b) The following shall apply to an owner‑occupied single‑family residence:
        (i) Each contractor shall provide the owner or his or
     her agent, either as part of the contract or as a separate printed statement given before the owner or his agent makes the first payment for labor, materials, fixtures, apparatus or machinery, the following:
        "THE LAW REQUIRES THAT THE CONTRACTOR SHALL SUBMIT A
     SWORN STATEMENT OF PERSONS FURNISHING LABOR, SERVICES, MATERIAL, FIXTURES, APPARATUS OR MACHINERY, FORMS OR FORM WORK BEFORE ANY PAYMENTS ARE REQUIRED TO BE MADE TO THE CONTRACTOR."
        If the owners of the property are persons living
     together, the aforesaid statement is conclusively presumed given to each such owners if given to one of them.
        (ii) Each subcontractor who has furnished, or is
     furnishing, labor, services, material, fixtures, apparatus or machinery, forms or form work in order to preserve his lien, shall notify the occupant either personally or by certified mail, return receipt requested, addressed to the occupant or his agent at the residence within 60 days from his first furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work, of his agreement to do so.
        The notice shall contain the name and address of the
     subcontractor or material man, the date he started to work or to deliver materials, the type of work done and to be done or the type of labor, services, material, fixtures, apparatus or machinery, forms or form work delivered and to be delivered, and the name of the contractor requesting the work. The notice shall also contain the following warning:
    "NOTICE TO OWNER
        The subcontractor providing this notice has performed
     work for or delivered material to your home improvement contractor. These services or materials are being used in the improvements to your residence and entitle the subcontractor to file a lien against your residence if the labor, services, material, fixtures, apparatus or machinery, forms or form work are not paid for by your home improvement contractor. A lien waiver will be provided to your contractor when the subcontractor is paid, and you are urged to request this waiver from your contractor when paying for your home improvements."
        (iii) The statement and the notices required by
     subdivisions (b)(i) and (b)(ii) of this Section shall be in at least 10 point boldface type. For purposes of this Section, notice by certified mail is considered served at the time of its mailing. Any notice given pursuant to subdivision (b)(ii) of this Section after 60 days by the subcontractor, however, shall preserve his or her lien, but only to the extent that the owner has not been prejudiced by payments made before receipt of the notice.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/6) (from Ch. 82, par. 6)
    Sec. 6. In no event shall it be necessary to fix or stipulate in any contract a time for the completion or a time for payment in order to obtain a lien under this act, provided, that the work is done or material furnished within three years from the commencement of said work or the commencement of furnishing said material.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/7)(from Ch. 82, par. 7)
    Sec. 7. Claim for lien; third parties; errors or overcharges; multiple buildings or lots.
    (a) No contractor shall be allowed to enforce such lien against or to the prejudice of any other creditor or incumbrancer or purchaser, unless within 4 months after completion, or if extra or additional work is done or labor, services, material, fixtures, apparatus or machinery, forms or form work is delivered therefor within 4 months after the completion of such extra or additional work or the final delivery of such extra or additional labor, services, material, fixtures, apparatus or machinery, forms or form work, he or she shall either bring an action to enforce his or her lien therefor or shall file in the office of the recorder of the county in which the building, erection or other improvement to be charged with the lien is situated, a claim for lien, verified by the affidavit of himself or herself, or his or her agent or employee, which shall consist of a brief statement of the claimant's contract, the balance due after allowing all credits, and a sufficiently correct description of the lot, lots or tracts of land to identify the same. Such claim for lien may be filed at any time after the claimant's contract is made, and as to the owner may be filed at any time after the contract is made and within 2 years after the completion of the contract, or the completion of any extra work or the furnishing of any extra labor, services, material, fixtures, apparatus or machinery, forms or form work thereunder, and as to such owner may be amended at any time before the final judgment. No such lien shall be defeated to the proper amount thereof because of an error or overcharging on the part of any person claiming a lien therefor under this Act, unless it shall be shown that such error or overcharge is made with intent to defraud; nor shall any such lien for material be defeated because of lack of proof that the material after the delivery thereof, actually entered into the construction of such building or improvement, although it be shown that such material was not actually used in the construction of such building or improvement; provided, that it is shown that such material was delivered either to the owner or his or her agent for that building or improvement, to be used in that building or improvement, or at the place where said building or improvement was being constructed, for the purpose of being used in construction or for the purpose of being employed in the process of construction as a means for assisting in the erection of the building or improvement in what is commonly termed forms or form work where concrete, cement or like material is used, in whole or in part.
    (b) In case of the construction of a number of buildings under contract between the same parties, it shall be sufficient in order to establish such lien for material, if it be shown that such material was in good faith delivered at one of these buildings for the purpose of being used in the construction of any one or all of such buildings, or delivered to the owner or his or her agent for such buildings, to be used therein; and such lien for such material shall attach to all of said buildings, together with the land upon which the same are being constructed, the same as in a single building or improvement. In the event the contract relates to 2 or more buildings on 2 or more lots or tracts of land, then all of these buildings and lots or tracts of land may be included in one statement of claims for a lien.
    (c) A statement that a party is a subcontractor shall not constitute an admission by the lien claimant that its status is that of subcontractor if it is later determined that the party with whom the lien claimant contracted was the owner or an agent of the owner.
    (d) A contractor for improvements of an owner‑occupied single‑family residence must give the owner written notice within 10 days after recording a lien against any property of the owner. The notice is served when it is sent or personally delivered. If timely notice is not given and, as a result, the owner has suffered damages before notice is given, the lien is extinguished to the extent of the damages. The mere recording of the lien claim is not considered damages. This subsection does not apply to subcontractors, and it applies only to contracts entered into after the effective date of this amendatory Act of the 96th General Assembly.
(Source: P.A. 96‑654, eff. 1‑1‑10.)

    (770 ILCS 60/8) (from Ch. 82, par. 8)
    Sec. 8. All liens or claims for lien which may arise or accrue under the terms of this act shall be assignable, and proceedings to enforce such liens or claims for lien may be maintained by and in the name of the assignee, who shall have as full and complete power to enforce the same as if such proceedings were taken under the provisions of this act by and in the name of the lien claimant.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/9) (from Ch. 82, par. 9)
    Sec. 9. If payment shall not be made to the contractor having a lien by virtue of this act of any amount due when the same becomes due, then such contractor may bring suit to enforce his lien in the circuit court in the county where the improvement is located, and in the event that the contract relates to two or more buildings or two or more lots or tracts of land, then all of said buildings and lots or tracts of land may be included in one complaint. Any two or more persons having liens on the same property may join in bringing such suit, setting forth their respective rights in their complaint; all lien claimants not made parties thereto may upon filing a petition to intervene become defendants and enforce their liens by counterclaim against all the parties to the suit; and the complaint shall not thereafter be dismissed as to any lien claimant, or as to the owner or owners of the premises without the consent of such lien claimant. The plaintiff and all defendants to such complaint may contest each other's right without any formal issue of record made up between them other than that shown upon the original complaint, as well with respect to the amount due as to the right to the benefit of the lien claimed: Provided, that if by such contest by co‑defendants any lien claimants be taken by surprise, the court may, in its discretion, as to such claim, grant a continuance. The court may render judgment against any party summoned and failing to appear, as in other cases of default. Such suit shall be commenced or counterclaim filed within two years after the completion of the contract, or completion of the extra or additional work, or furnishing of extra or additional material thereunder.
(Source: P.A. 79‑1358.)

    (770 ILCS 60/10) (from Ch. 82, par. 10)
    Sec. 10. Suits may be instituted under the provisions of this act in favor of administrators or executors, and may be maintained against the representatives in the interest of those against whom the cause of action accrued, and in suits instituted under the provisions of this act, the representatives of any party who may die pending the suit shall be made parties.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/11)(from Ch. 82, par. 11)
    Sec. 11. Averments in pleading; parties; dismissal; notice.
    (a) Any pleading asserting a claim for lien shall contain (i) a brief statement of the contract or contracts to which the person (hereinafter called the "claimant") asserting a claim for lien in the pleading is a party and by the terms of which the claimant is employed to furnish lienable services or material for the real property (herein called the "premises"), (ii) the date when the contract or contracts were dated or entered into, (iii) the date on which the claimant's work, labor or material labor, services, material, fixtures, apparatus or machinery, forms or form work was last performed or furnished, whether the claimant completed furnishing or performing its work, labor and material labor, services, material, fixtures, apparatus or machinery, forms or form work and if not why, (iv) the amount due and unpaid to the claimant, (v) a description of the premises, and (vi) such other facts as may be necessary for a full understanding of the rights of the parties. Where plans and specifications are by reference made a part of a contract that is required to be alleged in a pleading, it shall not be necessary to set the same out in the pleading or attached as exhibits, but the same may be produced on the trial of the suit. It shall not be necessary to include a statement of any contract to which the claimant is not a contracting party.
    (b) Each claimant shall make as parties to its pleading (hereinafter called "necessary parties") the owner of the premises, the contractor, all persons in the chain of contracts between the claimant and the owner, all persons who have asserted or may assert liens against the premises under this Act, and any other person against whose interest in the premises the claimant asserts a claim.
    (c) Necessary parties whose claims or interests are not disclosed by a document recorded at the time a proper lis pendens of the action under Section 2‑1901 of the Code of Civil Procedure has been recorded (or if the action is instituted as a mortgage foreclosure at the time a proper notice of foreclosure under Section 15‑1503 of the Code of Civil Procedure has been recorded) may be named and made parties under the description of "unknown necessary parties". Persons other than unknown necessary parties who may be interested in the premises but whose identities are unknown to the claimant may be named and made parties to the action under the description of "unknown owners".
    (d) A claimant may, in its, his or her discretion, make as parties (hereinafter called "permissible parties") to the action any other persons having a legal, equitable or possessory interest in or claim to the whole or any part of the premises, but failure to make any such permissible party a party to the action shall not defeat the lien, but the claim of each claimant asserting a lien claim under this Act in the action shall be subject to the interest of such permissible party not made a party, and the action shall not adversely affect the interest of any such permissible party not made a party and not served with notice by summons or publication in the action as provided in this Act.
    (e) The plaintiff shall cause notice to be given to all such necessary parties or cause them to be served by summons or by publication in like manner and upon the same conditions as in other civil actions, and the plaintiff's failure to do so, shall be grounds for judgment against him, her, or it on the merits. A claimant other than the plaintiff asserting a claim in the action under this Act shall also cause notice to be given to or cause summons to be served upon any necessary parties who have not been joined to the action, and his, her, or its failure to do so shall be grounds for judgment against him, her or it on the merits. Process may issue and service by publication may be had against those persons so named under the descriptions of "unknown necessary parties" or "unknown owners", and judgments entered against them shall be of the same effect as though they had been designated by and served under their proper names, provided that any judgment shall only bind any person served by publication with respect to their interests in the premises and liens asserted or assertable against the premises under this Act. A person who has been properly served in the action by summons or by publication by any claimant shall be deemed properly served by all claimants in the action regardless of whether such persons have been served before or after such claimants or any of them shall have appeared, filed their pleadings or become parties to the action, provided that nothing in this Section 11 shall excuse a claimant from joining all necessary parties to the claimant's pleading, whether as named parties, unknown necessary parties, or unknown owners, within the time permitted by this Act. Nothing in this Section 11 shall prevent service by publication in any proceeding brought under this Act where authorized by this Act in like manner and upon the same conditions as in other civil actions.
    (f) Any necessary party or permissible party who has not been joined to the action under his, her, or its proper name, may, upon application of such party to the court wherein the action is pending, be made or become a party at any time before final judgment, but such joinder shall not give such party any substantive rights not otherwise provided by law, or excuse failure to comply with the provisions of any applicable law.
    (g) No action under the provisions of this Act shall be voluntarily dismissed by the party bringing it without due notice to all parties to the action, and upon leave of court for good cause shown and upon terms approved by the court.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/12) (from Ch. 82, par. 12)
    Sec. 12. The court shall permit amendments to any part of the pleadings, and may issue process, make all orders, requiring parties to appear, and requiring notice to be given, that are or may be authorized in other civil actions and shall have the same power and jurisdiction of the parties and subject matter, and the rules of practice and proceedings in such cases shall be the same as in other civil cases, except as is otherwise provided in this act. The court shall have power to appoint receivers for property on which liens are sought to be enforced in the same manner for the same causes and for the same purposes as in cases of foreclosure of mortgages, as well as to complete any unfinished building where the same is deemed to be to the best interest of all the parties interested.
(Source: Laws 1935, p. 945.)

    (770 ILCS 60/13)(from Ch. 82, par. 13)
    Sec. 13. Defendant shall answer as in other civil actions.
    (a) The owner may make any defense against the contractor by way of counter claim that he could in any civil action for the payment of money, and may have the same right of recovery on proof of such in excess of the claim of the contractor against the contractor only, but for matters not growing out of the contract recovery shall be without prejudice to the rights of the sub‑contractors thereunder for payment out of the contract price or fund.
    (b) In any proceedings to enforce a lien on account of wages due for labor the claimant need file only an affidavit giving the amount due, between what dates the labor was performed and the kind of labor performed, and the court shall direct the amount due for wages as therein specified to be paid within a short day to be fixed by the court, unless within 10 days after the filing of the claim the amount claimed is contested by the owner or some other party to the suit. The party making such contest shall file an affidavit which shall state his defense to the allowance of the claim, and the court shall proceed at once to hear the evidence, and determine the merits of the claim, and in the event the allowance for wages is not paid within the time fixed by the court, the court shall order the premises sold to pay the amount in such manner as it directs.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/14) (from Ch. 82, par. 14)
    Sec. 14. In no case shall the want of preparation for trial of one claim delay the trial in respect to others, but trial shall be had upon issues between such parties as are prepared without references to issue between other parties; and when one creditor shall have obtained a judgment for the amount due, the court may order a sale of the premises on which the lien operates, or a part thereof, so as to satisfy the judgment: Provided, That the court may, for good cause shown, delay making any order for sale or distribution until the rights of all parties in interest are ascertained and settled by the court.
(Source: P.A. 79‑1358.)

    (770 ILCS 60/15) (from Ch. 82, par. 15)
    Sec. 15. Upon all questions arising between different contractors having liens under this act, no preference shall be given to him whose contract was made first, except the claim of any person for wages by him personally performed, shall be a preferred lien.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/16) (from Ch. 82, par. 16)
    Sec. 16. No incumbrance upon land, created before or after the making of the contract under the provisions of this act, shall operate upon the building erected, or materials furnished until a lien in favor of the persons having done work or furnished material shall have been satisfied, and upon questions arising between incumbrancers and lien creditors, all previous incumbrances shall be preferred to the extent of the value of the land at the time of making of the contract, and the lien creditor shall be preferred to the value of the improvements erected on said premises, and the court shall ascertain by jury or otherwise, as the case may require, what proportion of the proceeds of any sale shall be paid to the several parties in interest. All incumbrances, whether by mortgage, judgment or otherwise, charged and shown to be fraudulent, in respect to creditors, may be set aside by the court, and the premises freed and discharged from such fraudulent incumbrance.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/17) (from Ch. 82, par. 17)
    Sec. 17. Costs.
    (a) The costs of proceedings as between all parties to the suit shall be taxed equitably against the losing party, and where taxed against more than one party, shall be so taxed against all in favor of the proper party but equitably as between themselves; and the costs, as between creditors aforesaid in contests relative to each other's claims, shall be subject to the order of the court, and the same rule shall prevail in respect to costs growing out of the proceedings against and between incumbrances.
    (b) If the court specifically finds that the owner who contracted to have the improvements made failed to pay any lien claimant the full contract price, including extras, without just cause or right, the court may tax that owner, but not any other party, the reasonable attorney's fees of the lien claimant who had perfected and proven his or her claim.
    (c) If the court specifically finds that a lien claimant has brought an action under this Act without just cause or right, the court may tax the claimant the reasonable attorney's fees of the owner who contracted to have the improvements made and defended the action, but not those of any other party.
    (d) "Without just cause or right", as used in this Section, means a claim asserted by a lien claimant or a defense asserted by the owner who contracted to have the improvements made, which is not well grounded in fact and warranted by existing law or a good faith argument for the extension, modification, or reversal of existing law.
    (e) This amendatory Act of 1995 applies to any mechanics lien claim that is perfected on or after the effective date of this amendatory Act of 1995.
(Source: P.A. 89‑253, eff. 8‑8‑95.)

    (770 ILCS 60/18) (from Ch. 82, par. 18)
    Sec. 18. Whatever right or estate such owner had in the land at the time of making the contract may be sold in the same manner as other sales of real estate are made under orders of court. If any part of the premises can be separated from the residue, and sold without damage to the whole, and if the value thereof is sufficient to satisfy all the claims proved in the cause, the court may order a sale of that part.
(Source: P.A. 79‑1358.)

    (770 ILCS 60/19) (from Ch. 82, par. 19)
    Sec. 19. The court shall ascertain the amount due each lien creditor and shall direct the application of the proceeds of sale to be made to each in proportion to their several amounts, according to the provisions of this act, but the claims of all persons for labor as provided in Section 15 of this Act shall be first paid. If, upon making sale under this act of any or all premises, the proceeds of such sale shall not be sufficient to pay all claims of all parties, according to their rights, the judgment shall be credited by the amount of the sale and enforcement may proceed in favor of any creditor whose claims are not satisfied for the balance due as upon a deficiency judgment in the foreclosure of a mortgage and such deficiency judgment shall be a lien upon all real estate and other property of the party against whom it is entered to the same extent and under the same limitations as a judgment for the payment of money; and in case of excess of sales over the amount of the judgment, such excess be paid to the owner of the land, or to the person who may be entitled to the same, under the direction of the court.
(Source: P.A. 81‑251.)

    (770 ILCS 60/20) (from Ch. 82, par. 20)
    Sec. 20. Upon all sales under this Act the right of redemption shall exist in favor of the same persons, and may be made in the same manner as is or may be provided for redemption of real estate from sales under judgments for the payment of money.
(Source: P.A. 81‑251.)

    (770 ILCS 60/21)(from Ch. 82, par. 21)
    Sec. 21. Sub‑contractor defined; lien of sub‑contractor; notice; size of type; service of notice; amount of lien; default by contractor.
    (a) Subject to the provisions of Section 5, every mechanic, worker or other person who shall furnish any labor, services, material, fixtures, apparatus or machinery, forms or form work for the contractor, or shall furnish any material to be employed in the process of construction as a means for assisting in the erection of the building or improvement in what is commonly termed form or form work where concrete, cement or like material is used in whole or in part, shall be known under this Act as a sub‑contractor, and shall have a lien for the value thereof, with interest on such amount from the date the same is due, from the same time, on the same property as provided for the contractor, and, also, as against the creditors and assignees, and personal and legal representatives of the contractor, on the material, fixtures, apparatus or machinery furnished, and on the moneys or other conside

State Codes and Statutes

Statutes > Illinois > Chapter770 > 2254

    (770 ILCS 60/0.01) (from Ch. 82, par. 0.01)
    Sec. 0.01. Short title. This Act may be cited as the Mechanics Lien Act.
(Source: P.A. 86‑1324.)

    (770 ILCS 60/1)(from Ch. 82, par. 1)
    Sec. 1. Contractor defined; amount of lien; waiver of lien; attachment of lien; agreement to waive; when not enforceable.
    (a) Any person who shall by any contract or contracts, express or implied, or partly expressed or implied, with the owner of a lot or tract of land, or with one whom the owner has authorized or knowingly permitted to contract, to improve the lot or tract of land or for the purpose of improving the tract of land, or to manage a structure under construction thereon, is known under this Act as a contractor and has a lien upon the whole of such lot or tract of land and upon adjoining or adjacent lots or tracts of land of such owner constituting the same premises and occupied or used in connection with such lot or tract of land as a place of residence or business; and in case the contract relates to 2 or more buildings, on 2 or more lots or tracts of land, upon all such lots and tracts of land and improvements thereon for the amount due to him or her for the material, fixtures, apparatus, machinery, services or labor, and interest at the rate of 10% per annum from the date the same is due. This lien extends to an estate in fee, for life, for years, or any other estate or any right of redemption or other interest that the owner may have in the lot or tract of land at the time of making such contract or may subsequently acquire and this lien attaches as of the date of the contract.
    (b) As used in subsection (a) of this Section, "improve" means to furnish labor, services, material, fixtures, apparatus or machinery, forms or form work in the process of construction where cement, concrete or like material is used for the purpose of or in the building, altering, repairing or ornamenting any house or other building, walk or sidewalk, whether the walk or sidewalk is on the land or bordering thereon, driveway, fence or improvement or appurtenances to the lot or tract of land or connected therewith, and upon, over or under a sidewalk, street or alley adjoining; or fill, sod or excavate such lot or tract of land, or do landscape work thereon or therefor; or raise or lower any house thereon or remove any house thereto, or remove any house or other structure therefrom, or perform any services or incur any expense as an architect, structural engineer, professional engineer, land surveyor or property manager in, for or on a lot or tract of land for any such purpose; or drill any water well thereon; or furnish or perform labor or services as superintendent, time keeper, mechanic, laborer or otherwise, in the building, altering, repairing or ornamenting of the same; or furnish material, fixtures, apparatus, machinery, labor or services, forms or form work used in the process of construction where concrete, cement or like material is used, or drill any water well on the order of his agent, architect, structural engineer or superintendent having charge of the improvements, building, altering, repairing or ornamenting the same.
    (c) The taking of additional security by the contractor or sub‑contractor is not a waiver of any right of lien which he may have by virtue of this Act, unless made a waiver by express agreement of the parties and the waiver is not prohibited by this Act.
    (d) An agreement to waive any right to enforce or claim any lien under this Act where the agreement is in anticipation of and in consideration for the awarding of a contract or subcontract, either express or implied, to perform work or supply materials for an improvement upon real property is against public policy and unenforceable. This Section does not prohibit release of lien under subsection (b) of Section 35 of this Act or prohibit subordination of the lien, except as provided in Section 21.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/1.1)
    Sec. 1.1. (Repealed).
(Source: P.A. 87‑361. Repealed by P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/1.2)
    Sec. 1.2. Rental equipment liens. In addition to persons who would otherwise have a lien under this Act, any person, whether contractor or subcontractor, who leases construction equipment to another for use in the process of constructing a specific improvement to real estate, has a lien for the rental value of the construction equipment to the same extent and in the same manner as provided in this Act for other liens. This Section shall apply only if, and to the extent that, the equipment is used on or about the site of the improvement. This Section does not apply if the improvement is either a single family residence or a multi‑family residence of fewer than 12 units in a single building.
(Source: P.A. 95‑274, eff. 8‑17‑07.)

    (770 ILCS 60/2)(from Ch. 82, par. 2)
    Sec. 2. Labor, services, material, fixtures, apparatus or machinery, forms or form work furnished by mistake. Any person furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work for the erection of a building, or structure, or improvement, by mistake upon land owned by another than the party contracting as owner, shall have a lien for such labor, services, material, fixtures, apparatus or machinery, forms or form work upon such building, or structure or improvement, and the court, in the enforcement of such lien, shall order and direct such building, structure or improvement to be separately sold under its judgment, and the purchaser may remove the same within such reasonable time as the court may fix.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/3)(from Ch. 82, par. 3)
    Sec. 3. Labor, services, material, fixtures, apparatus or machinery, forms or form work furnished for lands of married person; lands held by husband and wife. If any such labor, services, material, fixtures, apparatus or machinery, forms or form work are performed upon lands belonging to any married person, with the married person's knowledge and not against the married person's protest in writing, as provided in Section 1 of this Act, in pursuance of a contract with the spouse of such married person, the person furnishing such labor, services, material, fixtures, apparatus or machinery, forms or form work shall have a lien upon such property, the same as if such contract had been made with the married person, and in case the title to such lands upon which improvements are made is held by married persons jointly, the lien given by this Act shall attach to such lands and improvements, if the improvements be made in pursuance of a contract with both of them, or in pursuance of a contract with either of them, and in such cases no claim of homestead right set up by a husband or wife shall defeat the lien given by this Act. For purposes of this Section, property shall be deemed to be held jointly if title is held by the parties either in tenancy by the entirety or jointly, with right of survivorship and not as tenants in common.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/4) (from Ch. 82, par. 4)
    Sec. 4. When the owner of the land shall fail to pay the contractor moneys justly due him under the contract at the time when the same should be paid, or fails to perform his part of the contract in any other manner, the contractor may discontinue work, and the contractor shall not be held liable for any delay on his part during the period of, or caused by, such breach of contract on the part of the owner; and if after such breach for the period of ten days the owner shall fail to comply with his contract, the contractor may abandon the work, and in such a case the contractor shall be entitled to enforce his lien for the value of what has been done, and the court shall adjust his claim and allow him a lien accordingly. In such cases all persons furnishing material which has not been incorporated in the improvement shall have the right to take possession of and remove the same if he so elects.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/5)(from Ch. 82, par. 5)
    Sec. 5. Statement of persons furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work notice to owner of waiver; size of type.
    (a) It shall be the duty of the contractor to give the owner, and the duty of the owner to require of the contractor, before the owner or his agent, architect, or superintendent shall pay or cause to be paid to the contractor or to his order any moneys or other consideration due or to become due to the contractor, or make or cause to be made to the contractor any advancement of any moneys or any other consideration, a statement in writing, under oath or verified by affidavit, of the names and addresses of all parties furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work and of the amounts due or to become due to each. Merchants and dealers in materials only shall not be required to make statements required in this Section.
    (b) The following shall apply to an owner‑occupied single‑family residence:
        (i) Each contractor shall provide the owner or his or
     her agent, either as part of the contract or as a separate printed statement given before the owner or his agent makes the first payment for labor, materials, fixtures, apparatus or machinery, the following:
        "THE LAW REQUIRES THAT THE CONTRACTOR SHALL SUBMIT A
     SWORN STATEMENT OF PERSONS FURNISHING LABOR, SERVICES, MATERIAL, FIXTURES, APPARATUS OR MACHINERY, FORMS OR FORM WORK BEFORE ANY PAYMENTS ARE REQUIRED TO BE MADE TO THE CONTRACTOR."
        If the owners of the property are persons living
     together, the aforesaid statement is conclusively presumed given to each such owners if given to one of them.
        (ii) Each subcontractor who has furnished, or is
     furnishing, labor, services, material, fixtures, apparatus or machinery, forms or form work in order to preserve his lien, shall notify the occupant either personally or by certified mail, return receipt requested, addressed to the occupant or his agent at the residence within 60 days from his first furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work, of his agreement to do so.
        The notice shall contain the name and address of the
     subcontractor or material man, the date he started to work or to deliver materials, the type of work done and to be done or the type of labor, services, material, fixtures, apparatus or machinery, forms or form work delivered and to be delivered, and the name of the contractor requesting the work. The notice shall also contain the following warning:
    "NOTICE TO OWNER
        The subcontractor providing this notice has performed
     work for or delivered material to your home improvement contractor. These services or materials are being used in the improvements to your residence and entitle the subcontractor to file a lien against your residence if the labor, services, material, fixtures, apparatus or machinery, forms or form work are not paid for by your home improvement contractor. A lien waiver will be provided to your contractor when the subcontractor is paid, and you are urged to request this waiver from your contractor when paying for your home improvements."
        (iii) The statement and the notices required by
     subdivisions (b)(i) and (b)(ii) of this Section shall be in at least 10 point boldface type. For purposes of this Section, notice by certified mail is considered served at the time of its mailing. Any notice given pursuant to subdivision (b)(ii) of this Section after 60 days by the subcontractor, however, shall preserve his or her lien, but only to the extent that the owner has not been prejudiced by payments made before receipt of the notice.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/6) (from Ch. 82, par. 6)
    Sec. 6. In no event shall it be necessary to fix or stipulate in any contract a time for the completion or a time for payment in order to obtain a lien under this act, provided, that the work is done or material furnished within three years from the commencement of said work or the commencement of furnishing said material.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/7)(from Ch. 82, par. 7)
    Sec. 7. Claim for lien; third parties; errors or overcharges; multiple buildings or lots.
    (a) No contractor shall be allowed to enforce such lien against or to the prejudice of any other creditor or incumbrancer or purchaser, unless within 4 months after completion, or if extra or additional work is done or labor, services, material, fixtures, apparatus or machinery, forms or form work is delivered therefor within 4 months after the completion of such extra or additional work or the final delivery of such extra or additional labor, services, material, fixtures, apparatus or machinery, forms or form work, he or she shall either bring an action to enforce his or her lien therefor or shall file in the office of the recorder of the county in which the building, erection or other improvement to be charged with the lien is situated, a claim for lien, verified by the affidavit of himself or herself, or his or her agent or employee, which shall consist of a brief statement of the claimant's contract, the balance due after allowing all credits, and a sufficiently correct description of the lot, lots or tracts of land to identify the same. Such claim for lien may be filed at any time after the claimant's contract is made, and as to the owner may be filed at any time after the contract is made and within 2 years after the completion of the contract, or the completion of any extra work or the furnishing of any extra labor, services, material, fixtures, apparatus or machinery, forms or form work thereunder, and as to such owner may be amended at any time before the final judgment. No such lien shall be defeated to the proper amount thereof because of an error or overcharging on the part of any person claiming a lien therefor under this Act, unless it shall be shown that such error or overcharge is made with intent to defraud; nor shall any such lien for material be defeated because of lack of proof that the material after the delivery thereof, actually entered into the construction of such building or improvement, although it be shown that such material was not actually used in the construction of such building or improvement; provided, that it is shown that such material was delivered either to the owner or his or her agent for that building or improvement, to be used in that building or improvement, or at the place where said building or improvement was being constructed, for the purpose of being used in construction or for the purpose of being employed in the process of construction as a means for assisting in the erection of the building or improvement in what is commonly termed forms or form work where concrete, cement or like material is used, in whole or in part.
    (b) In case of the construction of a number of buildings under contract between the same parties, it shall be sufficient in order to establish such lien for material, if it be shown that such material was in good faith delivered at one of these buildings for the purpose of being used in the construction of any one or all of such buildings, or delivered to the owner or his or her agent for such buildings, to be used therein; and such lien for such material shall attach to all of said buildings, together with the land upon which the same are being constructed, the same as in a single building or improvement. In the event the contract relates to 2 or more buildings on 2 or more lots or tracts of land, then all of these buildings and lots or tracts of land may be included in one statement of claims for a lien.
    (c) A statement that a party is a subcontractor shall not constitute an admission by the lien claimant that its status is that of subcontractor if it is later determined that the party with whom the lien claimant contracted was the owner or an agent of the owner.
    (d) A contractor for improvements of an owner‑occupied single‑family residence must give the owner written notice within 10 days after recording a lien against any property of the owner. The notice is served when it is sent or personally delivered. If timely notice is not given and, as a result, the owner has suffered damages before notice is given, the lien is extinguished to the extent of the damages. The mere recording of the lien claim is not considered damages. This subsection does not apply to subcontractors, and it applies only to contracts entered into after the effective date of this amendatory Act of the 96th General Assembly.
(Source: P.A. 96‑654, eff. 1‑1‑10.)

    (770 ILCS 60/8) (from Ch. 82, par. 8)
    Sec. 8. All liens or claims for lien which may arise or accrue under the terms of this act shall be assignable, and proceedings to enforce such liens or claims for lien may be maintained by and in the name of the assignee, who shall have as full and complete power to enforce the same as if such proceedings were taken under the provisions of this act by and in the name of the lien claimant.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/9) (from Ch. 82, par. 9)
    Sec. 9. If payment shall not be made to the contractor having a lien by virtue of this act of any amount due when the same becomes due, then such contractor may bring suit to enforce his lien in the circuit court in the county where the improvement is located, and in the event that the contract relates to two or more buildings or two or more lots or tracts of land, then all of said buildings and lots or tracts of land may be included in one complaint. Any two or more persons having liens on the same property may join in bringing such suit, setting forth their respective rights in their complaint; all lien claimants not made parties thereto may upon filing a petition to intervene become defendants and enforce their liens by counterclaim against all the parties to the suit; and the complaint shall not thereafter be dismissed as to any lien claimant, or as to the owner or owners of the premises without the consent of such lien claimant. The plaintiff and all defendants to such complaint may contest each other's right without any formal issue of record made up between them other than that shown upon the original complaint, as well with respect to the amount due as to the right to the benefit of the lien claimed: Provided, that if by such contest by co‑defendants any lien claimants be taken by surprise, the court may, in its discretion, as to such claim, grant a continuance. The court may render judgment against any party summoned and failing to appear, as in other cases of default. Such suit shall be commenced or counterclaim filed within two years after the completion of the contract, or completion of the extra or additional work, or furnishing of extra or additional material thereunder.
(Source: P.A. 79‑1358.)

    (770 ILCS 60/10) (from Ch. 82, par. 10)
    Sec. 10. Suits may be instituted under the provisions of this act in favor of administrators or executors, and may be maintained against the representatives in the interest of those against whom the cause of action accrued, and in suits instituted under the provisions of this act, the representatives of any party who may die pending the suit shall be made parties.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/11)(from Ch. 82, par. 11)
    Sec. 11. Averments in pleading; parties; dismissal; notice.
    (a) Any pleading asserting a claim for lien shall contain (i) a brief statement of the contract or contracts to which the person (hereinafter called the "claimant") asserting a claim for lien in the pleading is a party and by the terms of which the claimant is employed to furnish lienable services or material for the real property (herein called the "premises"), (ii) the date when the contract or contracts were dated or entered into, (iii) the date on which the claimant's work, labor or material labor, services, material, fixtures, apparatus or machinery, forms or form work was last performed or furnished, whether the claimant completed furnishing or performing its work, labor and material labor, services, material, fixtures, apparatus or machinery, forms or form work and if not why, (iv) the amount due and unpaid to the claimant, (v) a description of the premises, and (vi) such other facts as may be necessary for a full understanding of the rights of the parties. Where plans and specifications are by reference made a part of a contract that is required to be alleged in a pleading, it shall not be necessary to set the same out in the pleading or attached as exhibits, but the same may be produced on the trial of the suit. It shall not be necessary to include a statement of any contract to which the claimant is not a contracting party.
    (b) Each claimant shall make as parties to its pleading (hereinafter called "necessary parties") the owner of the premises, the contractor, all persons in the chain of contracts between the claimant and the owner, all persons who have asserted or may assert liens against the premises under this Act, and any other person against whose interest in the premises the claimant asserts a claim.
    (c) Necessary parties whose claims or interests are not disclosed by a document recorded at the time a proper lis pendens of the action under Section 2‑1901 of the Code of Civil Procedure has been recorded (or if the action is instituted as a mortgage foreclosure at the time a proper notice of foreclosure under Section 15‑1503 of the Code of Civil Procedure has been recorded) may be named and made parties under the description of "unknown necessary parties". Persons other than unknown necessary parties who may be interested in the premises but whose identities are unknown to the claimant may be named and made parties to the action under the description of "unknown owners".
    (d) A claimant may, in its, his or her discretion, make as parties (hereinafter called "permissible parties") to the action any other persons having a legal, equitable or possessory interest in or claim to the whole or any part of the premises, but failure to make any such permissible party a party to the action shall not defeat the lien, but the claim of each claimant asserting a lien claim under this Act in the action shall be subject to the interest of such permissible party not made a party, and the action shall not adversely affect the interest of any such permissible party not made a party and not served with notice by summons or publication in the action as provided in this Act.
    (e) The plaintiff shall cause notice to be given to all such necessary parties or cause them to be served by summons or by publication in like manner and upon the same conditions as in other civil actions, and the plaintiff's failure to do so, shall be grounds for judgment against him, her, or it on the merits. A claimant other than the plaintiff asserting a claim in the action under this Act shall also cause notice to be given to or cause summons to be served upon any necessary parties who have not been joined to the action, and his, her, or its failure to do so shall be grounds for judgment against him, her or it on the merits. Process may issue and service by publication may be had against those persons so named under the descriptions of "unknown necessary parties" or "unknown owners", and judgments entered against them shall be of the same effect as though they had been designated by and served under their proper names, provided that any judgment shall only bind any person served by publication with respect to their interests in the premises and liens asserted or assertable against the premises under this Act. A person who has been properly served in the action by summons or by publication by any claimant shall be deemed properly served by all claimants in the action regardless of whether such persons have been served before or after such claimants or any of them shall have appeared, filed their pleadings or become parties to the action, provided that nothing in this Section 11 shall excuse a claimant from joining all necessary parties to the claimant's pleading, whether as named parties, unknown necessary parties, or unknown owners, within the time permitted by this Act. Nothing in this Section 11 shall prevent service by publication in any proceeding brought under this Act where authorized by this Act in like manner and upon the same conditions as in other civil actions.
    (f) Any necessary party or permissible party who has not been joined to the action under his, her, or its proper name, may, upon application of such party to the court wherein the action is pending, be made or become a party at any time before final judgment, but such joinder shall not give such party any substantive rights not otherwise provided by law, or excuse failure to comply with the provisions of any applicable law.
    (g) No action under the provisions of this Act shall be voluntarily dismissed by the party bringing it without due notice to all parties to the action, and upon leave of court for good cause shown and upon terms approved by the court.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/12) (from Ch. 82, par. 12)
    Sec. 12. The court shall permit amendments to any part of the pleadings, and may issue process, make all orders, requiring parties to appear, and requiring notice to be given, that are or may be authorized in other civil actions and shall have the same power and jurisdiction of the parties and subject matter, and the rules of practice and proceedings in such cases shall be the same as in other civil cases, except as is otherwise provided in this act. The court shall have power to appoint receivers for property on which liens are sought to be enforced in the same manner for the same causes and for the same purposes as in cases of foreclosure of mortgages, as well as to complete any unfinished building where the same is deemed to be to the best interest of all the parties interested.
(Source: Laws 1935, p. 945.)

    (770 ILCS 60/13)(from Ch. 82, par. 13)
    Sec. 13. Defendant shall answer as in other civil actions.
    (a) The owner may make any defense against the contractor by way of counter claim that he could in any civil action for the payment of money, and may have the same right of recovery on proof of such in excess of the claim of the contractor against the contractor only, but for matters not growing out of the contract recovery shall be without prejudice to the rights of the sub‑contractors thereunder for payment out of the contract price or fund.
    (b) In any proceedings to enforce a lien on account of wages due for labor the claimant need file only an affidavit giving the amount due, between what dates the labor was performed and the kind of labor performed, and the court shall direct the amount due for wages as therein specified to be paid within a short day to be fixed by the court, unless within 10 days after the filing of the claim the amount claimed is contested by the owner or some other party to the suit. The party making such contest shall file an affidavit which shall state his defense to the allowance of the claim, and the court shall proceed at once to hear the evidence, and determine the merits of the claim, and in the event the allowance for wages is not paid within the time fixed by the court, the court shall order the premises sold to pay the amount in such manner as it directs.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/14) (from Ch. 82, par. 14)
    Sec. 14. In no case shall the want of preparation for trial of one claim delay the trial in respect to others, but trial shall be had upon issues between such parties as are prepared without references to issue between other parties; and when one creditor shall have obtained a judgment for the amount due, the court may order a sale of the premises on which the lien operates, or a part thereof, so as to satisfy the judgment: Provided, That the court may, for good cause shown, delay making any order for sale or distribution until the rights of all parties in interest are ascertained and settled by the court.
(Source: P.A. 79‑1358.)

    (770 ILCS 60/15) (from Ch. 82, par. 15)
    Sec. 15. Upon all questions arising between different contractors having liens under this act, no preference shall be given to him whose contract was made first, except the claim of any person for wages by him personally performed, shall be a preferred lien.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/16) (from Ch. 82, par. 16)
    Sec. 16. No incumbrance upon land, created before or after the making of the contract under the provisions of this act, shall operate upon the building erected, or materials furnished until a lien in favor of the persons having done work or furnished material shall have been satisfied, and upon questions arising between incumbrancers and lien creditors, all previous incumbrances shall be preferred to the extent of the value of the land at the time of making of the contract, and the lien creditor shall be preferred to the value of the improvements erected on said premises, and the court shall ascertain by jury or otherwise, as the case may require, what proportion of the proceeds of any sale shall be paid to the several parties in interest. All incumbrances, whether by mortgage, judgment or otherwise, charged and shown to be fraudulent, in respect to creditors, may be set aside by the court, and the premises freed and discharged from such fraudulent incumbrance.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/17) (from Ch. 82, par. 17)
    Sec. 17. Costs.
    (a) The costs of proceedings as between all parties to the suit shall be taxed equitably against the losing party, and where taxed against more than one party, shall be so taxed against all in favor of the proper party but equitably as between themselves; and the costs, as between creditors aforesaid in contests relative to each other's claims, shall be subject to the order of the court, and the same rule shall prevail in respect to costs growing out of the proceedings against and between incumbrances.
    (b) If the court specifically finds that the owner who contracted to have the improvements made failed to pay any lien claimant the full contract price, including extras, without just cause or right, the court may tax that owner, but not any other party, the reasonable attorney's fees of the lien claimant who had perfected and proven his or her claim.
    (c) If the court specifically finds that a lien claimant has brought an action under this Act without just cause or right, the court may tax the claimant the reasonable attorney's fees of the owner who contracted to have the improvements made and defended the action, but not those of any other party.
    (d) "Without just cause or right", as used in this Section, means a claim asserted by a lien claimant or a defense asserted by the owner who contracted to have the improvements made, which is not well grounded in fact and warranted by existing law or a good faith argument for the extension, modification, or reversal of existing law.
    (e) This amendatory Act of 1995 applies to any mechanics lien claim that is perfected on or after the effective date of this amendatory Act of 1995.
(Source: P.A. 89‑253, eff. 8‑8‑95.)

    (770 ILCS 60/18) (from Ch. 82, par. 18)
    Sec. 18. Whatever right or estate such owner had in the land at the time of making the contract may be sold in the same manner as other sales of real estate are made under orders of court. If any part of the premises can be separated from the residue, and sold without damage to the whole, and if the value thereof is sufficient to satisfy all the claims proved in the cause, the court may order a sale of that part.
(Source: P.A. 79‑1358.)

    (770 ILCS 60/19) (from Ch. 82, par. 19)
    Sec. 19. The court shall ascertain the amount due each lien creditor and shall direct the application of the proceeds of sale to be made to each in proportion to their several amounts, according to the provisions of this act, but the claims of all persons for labor as provided in Section 15 of this Act shall be first paid. If, upon making sale under this act of any or all premises, the proceeds of such sale shall not be sufficient to pay all claims of all parties, according to their rights, the judgment shall be credited by the amount of the sale and enforcement may proceed in favor of any creditor whose claims are not satisfied for the balance due as upon a deficiency judgment in the foreclosure of a mortgage and such deficiency judgment shall be a lien upon all real estate and other property of the party against whom it is entered to the same extent and under the same limitations as a judgment for the payment of money; and in case of excess of sales over the amount of the judgment, such excess be paid to the owner of the land, or to the person who may be entitled to the same, under the direction of the court.
(Source: P.A. 81‑251.)

    (770 ILCS 60/20) (from Ch. 82, par. 20)
    Sec. 20. Upon all sales under this Act the right of redemption shall exist in favor of the same persons, and may be made in the same manner as is or may be provided for redemption of real estate from sales under judgments for the payment of money.
(Source: P.A. 81‑251.)

    (770 ILCS 60/21)(from Ch. 82, par. 21)
    Sec. 21. Sub‑contractor defined; lien of sub‑contractor; notice; size of type; service of notice; amount of lien; default by contractor.
    (a) Subject to the provisions of Section 5, every mechanic, worker or other person who shall furnish any labor, services, material, fixtures, apparatus or machinery, forms or form work for the contractor, or shall furnish any material to be employed in the process of construction as a means for assisting in the erection of the building or improvement in what is commonly termed form or form work where concrete, cement or like material is used in whole or in part, shall be known under this Act as a sub‑contractor, and shall have a lien for the value thereof, with interest on such amount from the date the same is due, from the same time, on the same property as provided for the contractor, and, also, as against the creditors and assignees, and personal and legal representatives of the contractor, on the material, fixtures, apparatus or machinery furnished, and on the moneys or other conside

State Codes and Statutes


Back To Homepage

State Codes and Statutes

Statutes > Illinois > Chapter770 > 2254

    (770 ILCS 60/0.01) (from Ch. 82, par. 0.01)
    Sec. 0.01. Short title. This Act may be cited as the Mechanics Lien Act.
(Source: P.A. 86‑1324.)

    (770 ILCS 60/1)(from Ch. 82, par. 1)
    Sec. 1. Contractor defined; amount of lien; waiver of lien; attachment of lien; agreement to waive; when not enforceable.
    (a) Any person who shall by any contract or contracts, express or implied, or partly expressed or implied, with the owner of a lot or tract of land, or with one whom the owner has authorized or knowingly permitted to contract, to improve the lot or tract of land or for the purpose of improving the tract of land, or to manage a structure under construction thereon, is known under this Act as a contractor and has a lien upon the whole of such lot or tract of land and upon adjoining or adjacent lots or tracts of land of such owner constituting the same premises and occupied or used in connection with such lot or tract of land as a place of residence or business; and in case the contract relates to 2 or more buildings, on 2 or more lots or tracts of land, upon all such lots and tracts of land and improvements thereon for the amount due to him or her for the material, fixtures, apparatus, machinery, services or labor, and interest at the rate of 10% per annum from the date the same is due. This lien extends to an estate in fee, for life, for years, or any other estate or any right of redemption or other interest that the owner may have in the lot or tract of land at the time of making such contract or may subsequently acquire and this lien attaches as of the date of the contract.
    (b) As used in subsection (a) of this Section, "improve" means to furnish labor, services, material, fixtures, apparatus or machinery, forms or form work in the process of construction where cement, concrete or like material is used for the purpose of or in the building, altering, repairing or ornamenting any house or other building, walk or sidewalk, whether the walk or sidewalk is on the land or bordering thereon, driveway, fence or improvement or appurtenances to the lot or tract of land or connected therewith, and upon, over or under a sidewalk, street or alley adjoining; or fill, sod or excavate such lot or tract of land, or do landscape work thereon or therefor; or raise or lower any house thereon or remove any house thereto, or remove any house or other structure therefrom, or perform any services or incur any expense as an architect, structural engineer, professional engineer, land surveyor or property manager in, for or on a lot or tract of land for any such purpose; or drill any water well thereon; or furnish or perform labor or services as superintendent, time keeper, mechanic, laborer or otherwise, in the building, altering, repairing or ornamenting of the same; or furnish material, fixtures, apparatus, machinery, labor or services, forms or form work used in the process of construction where concrete, cement or like material is used, or drill any water well on the order of his agent, architect, structural engineer or superintendent having charge of the improvements, building, altering, repairing or ornamenting the same.
    (c) The taking of additional security by the contractor or sub‑contractor is not a waiver of any right of lien which he may have by virtue of this Act, unless made a waiver by express agreement of the parties and the waiver is not prohibited by this Act.
    (d) An agreement to waive any right to enforce or claim any lien under this Act where the agreement is in anticipation of and in consideration for the awarding of a contract or subcontract, either express or implied, to perform work or supply materials for an improvement upon real property is against public policy and unenforceable. This Section does not prohibit release of lien under subsection (b) of Section 35 of this Act or prohibit subordination of the lien, except as provided in Section 21.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/1.1)
    Sec. 1.1. (Repealed).
(Source: P.A. 87‑361. Repealed by P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/1.2)
    Sec. 1.2. Rental equipment liens. In addition to persons who would otherwise have a lien under this Act, any person, whether contractor or subcontractor, who leases construction equipment to another for use in the process of constructing a specific improvement to real estate, has a lien for the rental value of the construction equipment to the same extent and in the same manner as provided in this Act for other liens. This Section shall apply only if, and to the extent that, the equipment is used on or about the site of the improvement. This Section does not apply if the improvement is either a single family residence or a multi‑family residence of fewer than 12 units in a single building.
(Source: P.A. 95‑274, eff. 8‑17‑07.)

    (770 ILCS 60/2)(from Ch. 82, par. 2)
    Sec. 2. Labor, services, material, fixtures, apparatus or machinery, forms or form work furnished by mistake. Any person furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work for the erection of a building, or structure, or improvement, by mistake upon land owned by another than the party contracting as owner, shall have a lien for such labor, services, material, fixtures, apparatus or machinery, forms or form work upon such building, or structure or improvement, and the court, in the enforcement of such lien, shall order and direct such building, structure or improvement to be separately sold under its judgment, and the purchaser may remove the same within such reasonable time as the court may fix.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/3)(from Ch. 82, par. 3)
    Sec. 3. Labor, services, material, fixtures, apparatus or machinery, forms or form work furnished for lands of married person; lands held by husband and wife. If any such labor, services, material, fixtures, apparatus or machinery, forms or form work are performed upon lands belonging to any married person, with the married person's knowledge and not against the married person's protest in writing, as provided in Section 1 of this Act, in pursuance of a contract with the spouse of such married person, the person furnishing such labor, services, material, fixtures, apparatus or machinery, forms or form work shall have a lien upon such property, the same as if such contract had been made with the married person, and in case the title to such lands upon which improvements are made is held by married persons jointly, the lien given by this Act shall attach to such lands and improvements, if the improvements be made in pursuance of a contract with both of them, or in pursuance of a contract with either of them, and in such cases no claim of homestead right set up by a husband or wife shall defeat the lien given by this Act. For purposes of this Section, property shall be deemed to be held jointly if title is held by the parties either in tenancy by the entirety or jointly, with right of survivorship and not as tenants in common.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/4) (from Ch. 82, par. 4)
    Sec. 4. When the owner of the land shall fail to pay the contractor moneys justly due him under the contract at the time when the same should be paid, or fails to perform his part of the contract in any other manner, the contractor may discontinue work, and the contractor shall not be held liable for any delay on his part during the period of, or caused by, such breach of contract on the part of the owner; and if after such breach for the period of ten days the owner shall fail to comply with his contract, the contractor may abandon the work, and in such a case the contractor shall be entitled to enforce his lien for the value of what has been done, and the court shall adjust his claim and allow him a lien accordingly. In such cases all persons furnishing material which has not been incorporated in the improvement shall have the right to take possession of and remove the same if he so elects.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/5)(from Ch. 82, par. 5)
    Sec. 5. Statement of persons furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work notice to owner of waiver; size of type.
    (a) It shall be the duty of the contractor to give the owner, and the duty of the owner to require of the contractor, before the owner or his agent, architect, or superintendent shall pay or cause to be paid to the contractor or to his order any moneys or other consideration due or to become due to the contractor, or make or cause to be made to the contractor any advancement of any moneys or any other consideration, a statement in writing, under oath or verified by affidavit, of the names and addresses of all parties furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work and of the amounts due or to become due to each. Merchants and dealers in materials only shall not be required to make statements required in this Section.
    (b) The following shall apply to an owner‑occupied single‑family residence:
        (i) Each contractor shall provide the owner or his or
     her agent, either as part of the contract or as a separate printed statement given before the owner or his agent makes the first payment for labor, materials, fixtures, apparatus or machinery, the following:
        "THE LAW REQUIRES THAT THE CONTRACTOR SHALL SUBMIT A
     SWORN STATEMENT OF PERSONS FURNISHING LABOR, SERVICES, MATERIAL, FIXTURES, APPARATUS OR MACHINERY, FORMS OR FORM WORK BEFORE ANY PAYMENTS ARE REQUIRED TO BE MADE TO THE CONTRACTOR."
        If the owners of the property are persons living
     together, the aforesaid statement is conclusively presumed given to each such owners if given to one of them.
        (ii) Each subcontractor who has furnished, or is
     furnishing, labor, services, material, fixtures, apparatus or machinery, forms or form work in order to preserve his lien, shall notify the occupant either personally or by certified mail, return receipt requested, addressed to the occupant or his agent at the residence within 60 days from his first furnishing labor, services, material, fixtures, apparatus or machinery, forms or form work, of his agreement to do so.
        The notice shall contain the name and address of the
     subcontractor or material man, the date he started to work or to deliver materials, the type of work done and to be done or the type of labor, services, material, fixtures, apparatus or machinery, forms or form work delivered and to be delivered, and the name of the contractor requesting the work. The notice shall also contain the following warning:
    "NOTICE TO OWNER
        The subcontractor providing this notice has performed
     work for or delivered material to your home improvement contractor. These services or materials are being used in the improvements to your residence and entitle the subcontractor to file a lien against your residence if the labor, services, material, fixtures, apparatus or machinery, forms or form work are not paid for by your home improvement contractor. A lien waiver will be provided to your contractor when the subcontractor is paid, and you are urged to request this waiver from your contractor when paying for your home improvements."
        (iii) The statement and the notices required by
     subdivisions (b)(i) and (b)(ii) of this Section shall be in at least 10 point boldface type. For purposes of this Section, notice by certified mail is considered served at the time of its mailing. Any notice given pursuant to subdivision (b)(ii) of this Section after 60 days by the subcontractor, however, shall preserve his or her lien, but only to the extent that the owner has not been prejudiced by payments made before receipt of the notice.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/6) (from Ch. 82, par. 6)
    Sec. 6. In no event shall it be necessary to fix or stipulate in any contract a time for the completion or a time for payment in order to obtain a lien under this act, provided, that the work is done or material furnished within three years from the commencement of said work or the commencement of furnishing said material.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/7)(from Ch. 82, par. 7)
    Sec. 7. Claim for lien; third parties; errors or overcharges; multiple buildings or lots.
    (a) No contractor shall be allowed to enforce such lien against or to the prejudice of any other creditor or incumbrancer or purchaser, unless within 4 months after completion, or if extra or additional work is done or labor, services, material, fixtures, apparatus or machinery, forms or form work is delivered therefor within 4 months after the completion of such extra or additional work or the final delivery of such extra or additional labor, services, material, fixtures, apparatus or machinery, forms or form work, he or she shall either bring an action to enforce his or her lien therefor or shall file in the office of the recorder of the county in which the building, erection or other improvement to be charged with the lien is situated, a claim for lien, verified by the affidavit of himself or herself, or his or her agent or employee, which shall consist of a brief statement of the claimant's contract, the balance due after allowing all credits, and a sufficiently correct description of the lot, lots or tracts of land to identify the same. Such claim for lien may be filed at any time after the claimant's contract is made, and as to the owner may be filed at any time after the contract is made and within 2 years after the completion of the contract, or the completion of any extra work or the furnishing of any extra labor, services, material, fixtures, apparatus or machinery, forms or form work thereunder, and as to such owner may be amended at any time before the final judgment. No such lien shall be defeated to the proper amount thereof because of an error or overcharging on the part of any person claiming a lien therefor under this Act, unless it shall be shown that such error or overcharge is made with intent to defraud; nor shall any such lien for material be defeated because of lack of proof that the material after the delivery thereof, actually entered into the construction of such building or improvement, although it be shown that such material was not actually used in the construction of such building or improvement; provided, that it is shown that such material was delivered either to the owner or his or her agent for that building or improvement, to be used in that building or improvement, or at the place where said building or improvement was being constructed, for the purpose of being used in construction or for the purpose of being employed in the process of construction as a means for assisting in the erection of the building or improvement in what is commonly termed forms or form work where concrete, cement or like material is used, in whole or in part.
    (b) In case of the construction of a number of buildings under contract between the same parties, it shall be sufficient in order to establish such lien for material, if it be shown that such material was in good faith delivered at one of these buildings for the purpose of being used in the construction of any one or all of such buildings, or delivered to the owner or his or her agent for such buildings, to be used therein; and such lien for such material shall attach to all of said buildings, together with the land upon which the same are being constructed, the same as in a single building or improvement. In the event the contract relates to 2 or more buildings on 2 or more lots or tracts of land, then all of these buildings and lots or tracts of land may be included in one statement of claims for a lien.
    (c) A statement that a party is a subcontractor shall not constitute an admission by the lien claimant that its status is that of subcontractor if it is later determined that the party with whom the lien claimant contracted was the owner or an agent of the owner.
    (d) A contractor for improvements of an owner‑occupied single‑family residence must give the owner written notice within 10 days after recording a lien against any property of the owner. The notice is served when it is sent or personally delivered. If timely notice is not given and, as a result, the owner has suffered damages before notice is given, the lien is extinguished to the extent of the damages. The mere recording of the lien claim is not considered damages. This subsection does not apply to subcontractors, and it applies only to contracts entered into after the effective date of this amendatory Act of the 96th General Assembly.
(Source: P.A. 96‑654, eff. 1‑1‑10.)

    (770 ILCS 60/8) (from Ch. 82, par. 8)
    Sec. 8. All liens or claims for lien which may arise or accrue under the terms of this act shall be assignable, and proceedings to enforce such liens or claims for lien may be maintained by and in the name of the assignee, who shall have as full and complete power to enforce the same as if such proceedings were taken under the provisions of this act by and in the name of the lien claimant.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/9) (from Ch. 82, par. 9)
    Sec. 9. If payment shall not be made to the contractor having a lien by virtue of this act of any amount due when the same becomes due, then such contractor may bring suit to enforce his lien in the circuit court in the county where the improvement is located, and in the event that the contract relates to two or more buildings or two or more lots or tracts of land, then all of said buildings and lots or tracts of land may be included in one complaint. Any two or more persons having liens on the same property may join in bringing such suit, setting forth their respective rights in their complaint; all lien claimants not made parties thereto may upon filing a petition to intervene become defendants and enforce their liens by counterclaim against all the parties to the suit; and the complaint shall not thereafter be dismissed as to any lien claimant, or as to the owner or owners of the premises without the consent of such lien claimant. The plaintiff and all defendants to such complaint may contest each other's right without any formal issue of record made up between them other than that shown upon the original complaint, as well with respect to the amount due as to the right to the benefit of the lien claimed: Provided, that if by such contest by co‑defendants any lien claimants be taken by surprise, the court may, in its discretion, as to such claim, grant a continuance. The court may render judgment against any party summoned and failing to appear, as in other cases of default. Such suit shall be commenced or counterclaim filed within two years after the completion of the contract, or completion of the extra or additional work, or furnishing of extra or additional material thereunder.
(Source: P.A. 79‑1358.)

    (770 ILCS 60/10) (from Ch. 82, par. 10)
    Sec. 10. Suits may be instituted under the provisions of this act in favor of administrators or executors, and may be maintained against the representatives in the interest of those against whom the cause of action accrued, and in suits instituted under the provisions of this act, the representatives of any party who may die pending the suit shall be made parties.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/11)(from Ch. 82, par. 11)
    Sec. 11. Averments in pleading; parties; dismissal; notice.
    (a) Any pleading asserting a claim for lien shall contain (i) a brief statement of the contract or contracts to which the person (hereinafter called the "claimant") asserting a claim for lien in the pleading is a party and by the terms of which the claimant is employed to furnish lienable services or material for the real property (herein called the "premises"), (ii) the date when the contract or contracts were dated or entered into, (iii) the date on which the claimant's work, labor or material labor, services, material, fixtures, apparatus or machinery, forms or form work was last performed or furnished, whether the claimant completed furnishing or performing its work, labor and material labor, services, material, fixtures, apparatus or machinery, forms or form work and if not why, (iv) the amount due and unpaid to the claimant, (v) a description of the premises, and (vi) such other facts as may be necessary for a full understanding of the rights of the parties. Where plans and specifications are by reference made a part of a contract that is required to be alleged in a pleading, it shall not be necessary to set the same out in the pleading or attached as exhibits, but the same may be produced on the trial of the suit. It shall not be necessary to include a statement of any contract to which the claimant is not a contracting party.
    (b) Each claimant shall make as parties to its pleading (hereinafter called "necessary parties") the owner of the premises, the contractor, all persons in the chain of contracts between the claimant and the owner, all persons who have asserted or may assert liens against the premises under this Act, and any other person against whose interest in the premises the claimant asserts a claim.
    (c) Necessary parties whose claims or interests are not disclosed by a document recorded at the time a proper lis pendens of the action under Section 2‑1901 of the Code of Civil Procedure has been recorded (or if the action is instituted as a mortgage foreclosure at the time a proper notice of foreclosure under Section 15‑1503 of the Code of Civil Procedure has been recorded) may be named and made parties under the description of "unknown necessary parties". Persons other than unknown necessary parties who may be interested in the premises but whose identities are unknown to the claimant may be named and made parties to the action under the description of "unknown owners".
    (d) A claimant may, in its, his or her discretion, make as parties (hereinafter called "permissible parties") to the action any other persons having a legal, equitable or possessory interest in or claim to the whole or any part of the premises, but failure to make any such permissible party a party to the action shall not defeat the lien, but the claim of each claimant asserting a lien claim under this Act in the action shall be subject to the interest of such permissible party not made a party, and the action shall not adversely affect the interest of any such permissible party not made a party and not served with notice by summons or publication in the action as provided in this Act.
    (e) The plaintiff shall cause notice to be given to all such necessary parties or cause them to be served by summons or by publication in like manner and upon the same conditions as in other civil actions, and the plaintiff's failure to do so, shall be grounds for judgment against him, her, or it on the merits. A claimant other than the plaintiff asserting a claim in the action under this Act shall also cause notice to be given to or cause summons to be served upon any necessary parties who have not been joined to the action, and his, her, or its failure to do so shall be grounds for judgment against him, her or it on the merits. Process may issue and service by publication may be had against those persons so named under the descriptions of "unknown necessary parties" or "unknown owners", and judgments entered against them shall be of the same effect as though they had been designated by and served under their proper names, provided that any judgment shall only bind any person served by publication with respect to their interests in the premises and liens asserted or assertable against the premises under this Act. A person who has been properly served in the action by summons or by publication by any claimant shall be deemed properly served by all claimants in the action regardless of whether such persons have been served before or after such claimants or any of them shall have appeared, filed their pleadings or become parties to the action, provided that nothing in this Section 11 shall excuse a claimant from joining all necessary parties to the claimant's pleading, whether as named parties, unknown necessary parties, or unknown owners, within the time permitted by this Act. Nothing in this Section 11 shall prevent service by publication in any proceeding brought under this Act where authorized by this Act in like manner and upon the same conditions as in other civil actions.
    (f) Any necessary party or permissible party who has not been joined to the action under his, her, or its proper name, may, upon application of such party to the court wherein the action is pending, be made or become a party at any time before final judgment, but such joinder shall not give such party any substantive rights not otherwise provided by law, or excuse failure to comply with the provisions of any applicable law.
    (g) No action under the provisions of this Act shall be voluntarily dismissed by the party bringing it without due notice to all parties to the action, and upon leave of court for good cause shown and upon terms approved by the court.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/12) (from Ch. 82, par. 12)
    Sec. 12. The court shall permit amendments to any part of the pleadings, and may issue process, make all orders, requiring parties to appear, and requiring notice to be given, that are or may be authorized in other civil actions and shall have the same power and jurisdiction of the parties and subject matter, and the rules of practice and proceedings in such cases shall be the same as in other civil cases, except as is otherwise provided in this act. The court shall have power to appoint receivers for property on which liens are sought to be enforced in the same manner for the same causes and for the same purposes as in cases of foreclosure of mortgages, as well as to complete any unfinished building where the same is deemed to be to the best interest of all the parties interested.
(Source: Laws 1935, p. 945.)

    (770 ILCS 60/13)(from Ch. 82, par. 13)
    Sec. 13. Defendant shall answer as in other civil actions.
    (a) The owner may make any defense against the contractor by way of counter claim that he could in any civil action for the payment of money, and may have the same right of recovery on proof of such in excess of the claim of the contractor against the contractor only, but for matters not growing out of the contract recovery shall be without prejudice to the rights of the sub‑contractors thereunder for payment out of the contract price or fund.
    (b) In any proceedings to enforce a lien on account of wages due for labor the claimant need file only an affidavit giving the amount due, between what dates the labor was performed and the kind of labor performed, and the court shall direct the amount due for wages as therein specified to be paid within a short day to be fixed by the court, unless within 10 days after the filing of the claim the amount claimed is contested by the owner or some other party to the suit. The party making such contest shall file an affidavit which shall state his defense to the allowance of the claim, and the court shall proceed at once to hear the evidence, and determine the merits of the claim, and in the event the allowance for wages is not paid within the time fixed by the court, the court shall order the premises sold to pay the amount in such manner as it directs.
(Source: P.A. 94‑627, eff. 1‑1‑06.)

    (770 ILCS 60/14) (from Ch. 82, par. 14)
    Sec. 14. In no case shall the want of preparation for trial of one claim delay the trial in respect to others, but trial shall be had upon issues between such parties as are prepared without references to issue between other parties; and when one creditor shall have obtained a judgment for the amount due, the court may order a sale of the premises on which the lien operates, or a part thereof, so as to satisfy the judgment: Provided, That the court may, for good cause shown, delay making any order for sale or distribution until the rights of all parties in interest are ascertained and settled by the court.
(Source: P.A. 79‑1358.)

    (770 ILCS 60/15) (from Ch. 82, par. 15)
    Sec. 15. Upon all questions arising between different contractors having liens under this act, no preference shall be given to him whose contract was made first, except the claim of any person for wages by him personally performed, shall be a preferred lien.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/16) (from Ch. 82, par. 16)
    Sec. 16. No incumbrance upon land, created before or after the making of the contract under the provisions of this act, shall operate upon the building erected, or materials furnished until a lien in favor of the persons having done work or furnished material shall have been satisfied, and upon questions arising between incumbrancers and lien creditors, all previous incumbrances shall be preferred to the extent of the value of the land at the time of making of the contract, and the lien creditor shall be preferred to the value of the improvements erected on said premises, and the court shall ascertain by jury or otherwise, as the case may require, what proportion of the proceeds of any sale shall be paid to the several parties in interest. All incumbrances, whether by mortgage, judgment or otherwise, charged and shown to be fraudulent, in respect to creditors, may be set aside by the court, and the premises freed and discharged from such fraudulent incumbrance.
(Source: Laws 1903, p. 230.)

    (770 ILCS 60/17) (from Ch. 82, par. 17)
    Sec. 17. Costs.
    (a) The costs of proceedings as between all parties to the suit shall be taxed equitably against the losing party, and where taxed against more than one party, shall be so taxed against all in favor of the proper party but equitably as between themselves; and the costs, as between creditors aforesaid in contests relative to each other's claims, shall be subject to the order of the court, and the same rule shall prevail in respect to costs growing out of the proceedings against and between incumbrances.
    (b) If the court specifically finds that the owner who contracted to have the improvements made failed to pay any lien claimant the full contract price, including extras, without just cause or right, the court may tax that owner, but not any other party, the reasonable attorney's fees of the lien claimant who had perfected and proven his or her claim.
    (c) If the court specifically finds that a lien claimant has brought an action under this Act without just cause or right, the court may tax the claimant the reasonable attorney's fees of the owner who contracted to have the improvements made and defended the action, but not those of any other party.
    (d) "Without just cause or right", as used in this Section, means a claim asserted by a lien claimant or a defense asserted by the owner who contracted to have the improvements made, which is not well grounded in fact and warranted by existing law or a good faith argument for the extension, modification, or reversal of existing law.
    (e) This amendatory Act of 1995 applies to any mechanics lien claim that is perfected on or after the effective date of this amendatory Act of 1995.
(Source: P.A. 89‑253, eff. 8‑8‑95.)

    (770 ILCS 60/18) (from Ch. 82, par. 18)
    Sec. 18. Whatever right or estate such owner had in the land at the time of making the contract may be sold in the same manner as other sales of real estate are made under orders of court. If any part of the premises can be separated from the residue, and sold without damage to the whole, and if the value thereof is sufficient to satisfy all the claims proved in the cause, the court may order a sale of that part.
(Source: P.A. 79‑1358.)

    (770 ILCS 60/19) (from Ch. 82, par. 19)
    Sec. 19. The court shall ascertain the amount due each lien creditor and shall direct the application of the proceeds of sale to be made to each in proportion to their several amounts, according to the provisions of this act, but the claims of all persons for labor as provided in Section 15 of this Act shall be first paid. If, upon making sale under this act of any or all premises, the proceeds of such sale shall not be sufficient to pay all claims of all parties, according to their rights, the judgment shall be credited by the amount of the sale and enforcement may proceed in favor of any creditor whose claims are not satisfied for the balance due as upon a deficiency judgment in the foreclosure of a mortgage and such deficiency judgment shall be a lien upon all real estate and other property of the party against whom it is entered to the same extent and under the same limitations as a judgment for the payment of money; and in case of excess of sales over the amount of the judgment, such excess be paid to the owner of the land, or to the person who may be entitled to the same, under the direction of the court.
(Source: P.A. 81‑251.)

    (770 ILCS 60/20) (from Ch. 82, par. 20)
    Sec. 20. Upon all sales under this Act the right of redemption shall exist in favor of the same persons, and may be made in the same manner as is or may be provided for redemption of real estate from sales under judgments for the payment of money.
(Source: P.A. 81‑251.)

    (770 ILCS 60/21)(from Ch. 82, par. 21)
    Sec. 21. Sub‑contractor defined; lien of sub‑contractor; notice; size of type; service of notice; amount of lien; default by contractor.
    (a) Subject to the provisions of Section 5, every mechanic, worker or other person who shall furnish any labor, services, material, fixtures, apparatus or machinery, forms or form work for the contractor, or shall furnish any material to be employed in the process of construction as a means for assisting in the erection of the building or improvement in what is commonly termed form or form work where concrete, cement or like material is used in whole or in part, shall be known under this Act as a sub‑contractor, and shall have a lien for the value thereof, with interest on such amount from the date the same is due, from the same time, on the same property as provided for the contractor, and, also, as against the creditors and assignees, and personal and legal representatives of the contractor, on the material, fixtures, apparatus or machinery furnished, and on the moneys or other conside

Disclaimer
There is no confidential attorney-client relationship formed by using Laws.com website and information provided on this site is not legal advice. For legal advice, please contact your attorney. Attorneys listed on this website are not referred or endorsed by this website. By using Laws.com you agree to Laws.com Terms Of Use.
Copyright © 2017 Laws.com | All rights reserved

Loading..

Close Window

Loading, Please Wait!

This may take a second or two.