CHAPTER 2260. RESOLUTION OF CERTAIN CONTRACT CLAIMS AGAINST THE STATE

State Codes and Statutes

Statutes > Texas > Government-code > Title-10-general-government > Chapter-2260-resolution-of-certain-contract-claims-against-the-state

GOVERNMENT CODE

TITLE 10. GENERAL GOVERNMENT

SUBTITLE F. STATE AND LOCAL CONTRACTS AND FUND MANAGEMENT

CHAPTER 2260. RESOLUTION OF CERTAIN CONTRACT CLAIMS AGAINST THE

STATE

SUBCHAPTER A. GENERAL PROVISIONS

Sec. 2260.001. DEFINITIONS. In this chapter:

(1) "Contract" means a written contract between a unit of state

government and a contractor for goods or services, or for a

project as defined by Section 2166.001. The term does not include

a contract subject to Section 201.112, Transportation Code.

(2) "Contractor" means an independent contractor who has entered

into a contract directly with a unit of state government. The

term does not include:

(A) a contractor's subcontractor, officer, employee, agent, or

other person furnishing goods or services to a contractor;

(B) an employee of a unit of state government; or

(3) "Institution of higher education" has the meaning assigned

by Section 61.003, Education Code.

(4) "Unit of state government" means the state or an agency,

department, commission, bureau, board, office, council, court, or

other entity that is in any branch of state government and that

is created by the constitution or a statute of this state,

including a university system or institution of higher education.

The term does not include a county, municipality, court of a

county or municipality, special purpose district, or other

political subdivision of this state.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.002. APPLICABILITY. This chapter does not apply to:

(1) a claim for personal injury or wrongful death arising from

the breach of a contract; or

(2) a contract executed or awarded on or before August 30, 1999.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999. Amended by Acts 2001, 77th Leg., ch. 1422, Sec. 14.07, eff.

Sept. 1, 2001.

Sec. 2260.003. DAMAGES. (a) The total amount of money

recoverable on a claim for breach of contract under this chapter

may not, after deducting the amount specified in Subsection (b),

exceed an amount equal to the sum of:

(1) the balance due and owing on the contract price;

(2) the amount or fair market value of orders or requests for

additional work made by a unit of state government to the extent

that the orders or requests for additional work were actually

performed; and

(3) any delay or labor-related expense incurred by the

contractor as a result of an action of or a failure to act by the

unit of state government or a party acting under the supervision

or control of the unit of state government.

(b) Any amount owed the unit of state government for work not

performed under a contract or in substantial compliance with its

terms shall be deducted from the amount in Subsection (a).

(1) consequential or similar damages, except delays or

labor-related expenses described by Subsection (a)(3);

(2) exemplary damages;

(3) any damages based on an unjust enrichment theory;

(4) attorney's fees; or

(5) home office overhead.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999. Amended by Acts 2001, 77th Leg., ch. 1272, Sec. 8.01, eff.

June 15, 2001; Acts 2001, 77th Leg., ch. 1422, Sec. 14.08, eff.

Sept. 1, 2001.

Amended by:

Acts 2005, 79th Leg., Ch.

988, Sec. 1, eff. September 1, 2005.

Sec. 2260.004. REQUIRED CONTRACT PROVISION. (a) Each unit of

state government that enters into a contract to which this

chapter applies shall include as a term of the contract a

provision stating that the dispute resolution process used by the

unit of state government under this chapter must be used to

attempt to resolve a dispute arising under the contract.

(b) The attorney general shall provide assistance to a unit of

state government in developing the contract provision required by

this section.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.005. EXCLUSIVE PROCEDURE. Subject to Section

2260.007, the procedures contained in this chapter are exclusive

and required prerequisites to suit in accordance with Chapter

107, Civil Practice and Remedies Code. This chapter does not

prevent a contractor sued by a unit of state government from

asserting a counterclaim or right of offset against the unit of

state government in the court in which the unit of state

government files the suit.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999. Amended by Acts 2001, 77th Leg., ch. 1158, Sec. 72, eff.

June 15, 2001; Acts 2001, 77th Leg., ch. 1272, Sec. 8.02, eff.

June 15, 2001; Acts 2001, 77th Leg., ch. 1422, Sec. 14.09, eff.

Sept. 1, 2001.

Amended by:

Acts 2005, 79th Leg., Ch.

988, Sec. 2, eff. September 1, 2005.

Sec. 2260.006. SOVEREIGN IMMUNITY. This chapter does not waive

sovereign immunity to suit or liability.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.007. LEGISLATIVE AUTHORITY RETAINED; INTERPRETATION OF

CHAPTER. (a) Notwithstanding Section 2260.005, the legislature

retains the authority to deny or grant a waiver of immunity to

suit against a unit of state government by statute, resolution,

or any other means the legislature may determine appropriate.

(b) This chapter does not and may not be interpreted to:

(1) divest the legislature of the authority to grant permission

to sue a unit of state government on the terms, conditions, and

procedures that the legislature may specify in the measure

granting the permission;

(2) require that the legislature, in granting or denying

permission to sue a unit of state government, comply with this

chapter; or

(3) limit in any way the effect of a legislative grant of

permission to sue a unit of state government unless the grant

itself provides that this chapter may have that effect.

Added by Acts 2001, 77th Leg., ch. 1158, Sec. 73, eff. June 15,

2001; Acts 2001, 77th Leg., ch. 1272, Sec. 8.03, eff. June 15,

2001; Acts 2001, 77th Leg., ch. 1422, Sec. 14.10, eff. Sept. 1,

2001. Amended by Acts 2003, 78th Leg., ch. 1276, Sec. 9.021, eff.

Sept. 1, 2003.

SUBCHAPTER B. NEGOTIATION OF CLAIM

Sec. 2260.051. CLAIM FOR BREACH OF CONTRACT; NOTICE. (a) A

contractor may make a claim against a unit of state government

for breach of a contract between the unit of state government and

the contractor. The unit of state government may assert a

counterclaim against the contractor.

(b) A contractor must provide written notice to the unit of

state government of a claim for breach of contract not later than

the 180th day after the date of the event giving rise to the

claim.

(1) the nature of the alleged breach;

(2) the amount the contractor seeks as damages; and

(3) the legal theory of recovery.

(d) A unit of state government must assert, in a writing

delivered to the contractor, any counterclaim not later than the

60th day after the date of notice under Subsection (b). A unit

of state government that does not comply with this subsection

waives the right to assert the counterclaim.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Amended by:

Acts 2005, 79th Leg., Ch.

988, Sec. 3, eff. September 1, 2005.

Sec. 2260.052. NEGOTIATION. (a) The chief administrative

officer or, if designated in the contract, another officer of the

unit of state government shall examine the claim and any

counterclaim and negotiate with the contractor in an effort to

resolve them. The negotiation must begin not later than the

120th day after the date the claim is received.

(b) Repealed by Acts 2005, 79th Leg., Ch. 988, Sec. 8, eff.

September 1, 2005.

shall develop rules to govern the negotiation and mediation of a

claim under this section. If a unit of state government does not

have rulemaking authority, that unit shall follow the rules

adopted by the attorney general. A model rule for negotiation and

mediation under this chapter shall be provided for voluntary

adoption by units of state government through the coordinated

efforts of the State Office of Administrative Hearings and the

office of the attorney general.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Amended by:

Acts 2005, 79th Leg., Ch.

988, Sec. 4, eff. September 1, 2005.

Acts 2005, 79th Leg., Ch.

988, Sec. 8, eff. September 1, 2005.

Sec. 2260.053. PARTIAL RESOLUTION OF CLAIM. (a) If the

negotiation under Section 2260.052 results in the resolution of

some disputed issues by agreement or in a settlement, the parties

shall reduce the agreement or settlement to writing and each

party shall sign the agreement or settlement.

(b) A partial settlement or resolution of a claim does not waive

a party's rights under this chapter as to the parts of the claim

that are not resolved.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.054. PAYMENT OF CLAIM FROM APPROPRIATED FUNDS. A unit

of state government may pay a claim resolved in accordance with

this subchapter only from money appropriated to it for payment of

contract claims or for payment of the contract that is the

subject of the claim. If money previously appropriated for

payment of contract claims or payment of the contract is

insufficient to pay the claim or settlement, the balance of the

claim may be paid only from money appropriated by the legislature

for payment of the claim.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.055. INCOMPLETE RESOLUTION. If a claim is not

entirely resolved under Section 2260.052 on or before the 270th

day after the date the claim is filed with the unit of state

government, unless the parties agree in writing to an extension

of time, the contractor may file a request for a hearing under

Subchapter C.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.056. MEDIATION. (a) Before the 120th day after the

date the claim is filed with the unit of state government and

before the expiration of any extension of time under Section

2260.055, the parties may agree to mediate a claim made under

this chapter.

(b) The mediation shall be conducted in accordance with rules

adopted under Section 2260.052(c).

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Amended by:

Acts 2005, 79th Leg., Ch.

988, Sec. 5, eff. September 1, 2005.

SUBCHAPTER C. CONTESTED CASE HEARING

Sec. 2260.101. DEFINITION. In this subchapter, "office" means

the State Office of Administrative Hearings.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.102. REQUEST FOR HEARING. (a) If a contractor is not

satisfied with the results of negotiation with a unit of state

government under Section 2260.052, the contractor may file a

request for a hearing with the unit of state government.

(b) The request must:

(1) state the factual and legal basis for the claim; and

(2) request that the claim be referred to the State Office of

Administrative Hearings for a contested case hearing.

state government shall refer the claim to the State Office of

Administrative Hearings for a contested case hearing under

Chapter 2001, Government Code, as to the issues raised in the

request.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.103. HEARING FEE. (a) The chief administrative law

judge of the office may set a fee for a hearing before the office

under this subchapter.

(b) The chief administrative law judge of the office shall set

the fee in an amount that:

(1) is not less than $250; and

(2) allows the office to recover all or a substantial part of

its costs in holding hearings.

establish a graduated fee scale, increasing the fee in relation

to the amount in controversy.

(d) The office may:

(1) assess the fee against the party who does not prevail in the

hearing; or

(2) apportion the fee against the parties in an equitable

manner.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.104. HEARING. (a) An administrative law judge of the

office shall conduct a hearing in accordance with the procedures

adopted by the chief administrative law judge of the office.

(b) Within a reasonable time after the conclusion of the

hearing, the administrative law judge shall issue a written

decision containing the administrative law judge's findings and

recommendations.

pleadings filed with the office and the evidence received.

(d) The decision must include:

(1) the findings of fact and conclusions of law on which the

administrative law judge's decision is based; and

(2) a summary of the evidence.

(e) In a contested case hearing under this subchapter:

(1) the decision may not be appealed except for abuse of

discretion; and

(2) the state agency may not change the finding of fact or

conclusion of law, nor vacate or modify an order as provided in

Section 2001.058(e).

(f) Subchapter G, Chapter 2001, does not apply to a hearing

under this section.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Amended by:

Acts 2005, 79th Leg., Ch.

988, Sec. 6, eff. September 1, 2005.

Sec. 2260.105. PAYMENT OF CLAIM. (a) The unit of state

government shall pay the amount of the claim or part of the claim

if:

(1) the administrative law judge finds, by a preponderance of

the evidence, that under the laws of this state the claim or part

of the claim is valid; and

(2) the total amount of damages, after taking into account any

counterclaim, is less than $250,000.

(a-1) The unit of state government shall pay that part of the

claim that is less than $250,000 if:

(1) the administrative law judge finds, by a preponderance of

the evidence, that under the laws of this state the claim or part

of the claim is valid; and

(2) the total amount of the damages, after taking into account

any counterclaim, equals or exceeds $250,000.

(b) A unit of state government shall pay a claim under this

subchapter from money appropriated to it for payment of contract

claims or for payment of the contract that is the subject of the

claim. If money previously appropriated for payment of contract

claims or payment of the contract is insufficient to pay the

claim, the balance of the claim may be paid only from money

appropriated by the legislature for payment of the claim.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Amended by:

Acts 2005, 79th Leg., Ch.

988, Sec. 7, eff. September 1, 2005.

Sec. 2260.1055. REPORT AND RECOMMENDATION TO LEGISLATURE. (a)

If, after a hearing, the administrative law judge determines that

a claim involves damages of $250,000 or more, the administrative

law judge shall issue a written report containing the

administrative law judge's findings and recommendations to the

legislature.

(b) The administrative law judge may recommend that the

legislature:

(1) appropriate money to pay the claim or part of the claim if

the administrative law judge finds, by a preponderance of the

evidence, that under the laws of this state the claim or part of

the claim is valid; or

(2) not appropriate money to pay the claim and that consent to

suit under Chapter 107, Civil Practice and Remedies Code, be

denied.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.106. PREJUDGMENT INTEREST. Chapter 304, Finance Code,

applies to a judgment awarded to a claimant under this chapter,

except that the applicable rate of interest may not exceed six

percent.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.107. EXECUTION ON STATE PROPERTY NOT AUTHORIZED. This

chapter does not authorize execution on property owned by the

state or a unit of state government.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

Sec. 2260.108. DEFENSE BY ATTORNEY GENERAL. (a) The attorney

general shall defend a unit of state government in a contested

case hearing covered by this chapter.

(b) The attorney general may settle or compromise the portion of

a claim that may result in state liability under this chapter.

Added by Acts 1999, 76th Leg., ch. 1352, Sec. 9, eff. Aug. 30,

1999.

State Codes and Statutes

State Codes and Statutes

State Codes and Statutes

State Codes and Statutes

Loading..

Loading, Please Wait!