State Codes and Statutes

Statutes > Vermont > Title-30 > Chapter-5 > 248a

§ 248a. Certificate of public good for communications facilities

(a) Certificate. Notwithstanding any other provision of law, if the applicant seeks approval for the construction or installation of telecommunications facilities that are to be interconnected with other telecommunications facilities proposed or already in existence, the applicant may obtain a certificate of public good issued by the public service board under this section, which the board may grant if it finds that the facilities will promote the general good of the state consistent with subsection 202c(b) of this title. A single application may seek approval of one or more telecommunications facilities.

(b) Definitions. For the purposes of this section:

(1) "Telecommunications facility" means a communications facility that transmits and receives signals to and from a local, state, national, or international network used primarily for two-way communications for commercial, industrial, municipal, county, or state purposes and any associated support structure that is proposed for construction or installation which is primarily for communications purposes, and any ancillary improvements that are proposed for construction or installation and are primarily intended to serve the communications facilities or support structure.

(2) An applicant may seek approval of construction or installation of a telecommunications facility whether or not the telecommunications facility is attached to an existing structure.

(c) Findings. Before the public service board issues a certificate of public good under this section, it shall find that:

(1) The proposed facility will not have an undue adverse effect on aesthetics, historic sites, air and water purity, the natural environment, and the public health and safety, with due consideration having been given to the relevant criteria specified in subsection 1424a(d) and subdivisions 6086(a)(1) through (8) and (9)(K) of Title 10.

(2) Unless there is good cause to find otherwise, substantial deference has been given to the land conservation measures in the plans of the affected municipalities and the recommendations of the municipal legislative bodies and the municipal and regional planning commissions regarding the municipal and regional plans, respectively. Nothing in this section or other provision of law shall prevent a municipal body from basing its recommendations on an ordinance adopted under 24 V.S.A. § 2291(19) or bylaw adopted under 24 V.S.A. chapter 117 by the municipality in which the facility is located.

(d) Existing permits. When issuing a certificate of public good under this section, the board shall give due consideration to all conditions in an existing state or local permit and shall harmonize the conditions in the certificate of public good with the existing permit conditions to the extent feasible.

(e) Notice. No less than 45 days prior to filing a petition for a certificate of public good under this section, the applicant shall serve written notice of an application to be filed with the board pursuant to this section to the legislative bodies and municipal and regional planning commissions in the communities in which the applicant proposes to construct or install facilities; the secretary of the agency of natural resources; the commissioner of the department of public service and its director for public advocacy; and the landowners of record of property adjoining the project sites. In addition, at least one copy of each application shall be filed with each of these municipal and regional planning commissions. Upon motion or otherwise, the public service board shall direct that further public or personal notice be provided if the board finds that such further notice will not unduly delay consideration of the merits and that additional notice is necessary for fair consideration of the application.

(f) Review period. Unless the public service board identifies that an application raises a significant issue, the board shall issue a final determination on an application filed pursuant to this section within 90 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 90 days of the date on which the clerk of the board notifies the applicant that the filing is complete. If the board rules that an application raises a significant issue, it shall issue a final determination on an application filed pursuant to this section within 180 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 180 days of the date on which the clerk of the board notifies the applicant that the filing is complete.

(g) Letter of intent. Nothing in this section shall be construed to prohibit an applicant from executing a letter of intent or entering into a contract before the issuance of a certificate of public good under this section, provided that the obligations under that letter of intent or contract are made subject to compliance with the requirements of this section.

(h) Exemptions from other law. An applicant using the procedures provided in this section shall not be required to obtain a permit or permit amendment or other approval under the provisions of chapter 117 of Title 24 or chapter 151 of Title 10 for the facilities subject to the application or to a certificate of public good issued pursuant to this section. Ordinances adopted pursuant to subdivision 2291(19) of Title 24 or a municipal charter that would otherwise apply to the construction or installation of facilities subject to this section are preempted. Disputes over jurisdiction under this section shall be resolved by the public service board, subject to appeal as provided by section 12 of this title. An applicant that has obtained or been denied a permit or permit amendment under the provisions of Title 24 or chapter 151 of Title 10 for the construction of a telecommunications facility may not apply for approval from the board for the same or substantially the same facility, except that an applicant may seek approval for a modification to such a facility.

(i) Sunset of board authority. Effective July 1, 2011, no new applications for certificates of public good under this section may be considered by the board.

(j)(1) Minor applications. The board may, subject to such conditions as it may otherwise lawfully impose, issue a certificate of public good in accordance with the provisions of this subsection and without the notice and hearings required by any provision other than subdivision (2) of this subsection if the board finds that such facilities will be of limited size and scope, and the petition does not raise a significant issue with respect to the substantive criteria of this section. If an applicant requests approval of multiple telecommunications facilities in a single application under this section, the board may issue a certificate of public good in accordance with the provisions of this subsection for all or some of the telecommunications facilities described in the petition.

(2)(A) Any party seeking to proceed under the procedures authorized by this subsection shall file a proposed certificate of public good and proposed findings of fact with its petition, and provide notice and a copy of the petition, proposed certificate of public good, and proposed findings of fact to the commissioner of the department of public service and its director for public advocacy, the secretary of the agency of natural resources, and each of the legislative bodies and municipal and regional planning commissions in the communities in which the applicant proposes to construct or install facilities. The applicant shall give written notice of the proposed certificate to the landowners of record of property adjoining the project site or sites unless the board has previously determined on request of the applicant that good cause exists to waive or modify the notice requirement with respect to such landowners. Such notice shall request comment to the board within 21 days of the notice on the question of whether the petition raises a significant issue with respect to the substantive criteria of this section. If the board finds that a petition raises a significant issue with respect to the substantive criteria of this section, the board shall hear evidence on any such issue.

(B) Any waiver or modification of notice to adjoining landowners under this subsection shall be based on a determination that the landowners subject to the waiver or modification could not reasonably be affected by one or more of the proposed facilities, and that notice to such landowners would constitute a significant administrative burden without corresponding public benefit.

(C) If the board accepts a request to consider an application under the procedures of this subsection, then unless the public service board subsequently determines that an application raises a significant issue, the board shall issue a final determination on an application filed pursuant to this subsection within 45 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 45 days of the date on which the clerk of the board notifies the applicant that the filing is complete. If, subsequent to acceptance of an application under this subsection, the board rules that an application raises a significant issue, it shall issue a final determination on an application filed pursuant to this subsection within 90 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 90 days of the date on which the clerk of the board notifies the applicant that the filing is complete.

(D) If the board denies a request to consider an application under the procedures of this subsection, a filing made under this subsection that the board has found to be complete shall be deemed to satisfy notice requirements of subsection (e) of this section, and the periods stated under subsection (f) of this section shall run from the date of the board's denial of such request.

(k) Rules. The public service board may issue rules or orders implementing and interpreting this section. In developing such rules and orders, the board shall seek to simplify the application and review process as appropriate and may by rule or order waive the requirements of this section that the board determines are not applicable to telecommunications facilities of limited size or scope. Determination by the board that a petition raises a substantial issue with regard to one or more substantive criteria of this section shall not prevent the board from waiving other substantive criteria that it has determined are not applicable to such a telecommunications facility. (Added 2007, No. 79, § 17, eff. June 9, 2007; 2009, No. 54, § 44, eff. June 1, 2009.)

State Codes and Statutes

Statutes > Vermont > Title-30 > Chapter-5 > 248a

§ 248a. Certificate of public good for communications facilities

(a) Certificate. Notwithstanding any other provision of law, if the applicant seeks approval for the construction or installation of telecommunications facilities that are to be interconnected with other telecommunications facilities proposed or already in existence, the applicant may obtain a certificate of public good issued by the public service board under this section, which the board may grant if it finds that the facilities will promote the general good of the state consistent with subsection 202c(b) of this title. A single application may seek approval of one or more telecommunications facilities.

(b) Definitions. For the purposes of this section:

(1) "Telecommunications facility" means a communications facility that transmits and receives signals to and from a local, state, national, or international network used primarily for two-way communications for commercial, industrial, municipal, county, or state purposes and any associated support structure that is proposed for construction or installation which is primarily for communications purposes, and any ancillary improvements that are proposed for construction or installation and are primarily intended to serve the communications facilities or support structure.

(2) An applicant may seek approval of construction or installation of a telecommunications facility whether or not the telecommunications facility is attached to an existing structure.

(c) Findings. Before the public service board issues a certificate of public good under this section, it shall find that:

(1) The proposed facility will not have an undue adverse effect on aesthetics, historic sites, air and water purity, the natural environment, and the public health and safety, with due consideration having been given to the relevant criteria specified in subsection 1424a(d) and subdivisions 6086(a)(1) through (8) and (9)(K) of Title 10.

(2) Unless there is good cause to find otherwise, substantial deference has been given to the land conservation measures in the plans of the affected municipalities and the recommendations of the municipal legislative bodies and the municipal and regional planning commissions regarding the municipal and regional plans, respectively. Nothing in this section or other provision of law shall prevent a municipal body from basing its recommendations on an ordinance adopted under 24 V.S.A. § 2291(19) or bylaw adopted under 24 V.S.A. chapter 117 by the municipality in which the facility is located.

(d) Existing permits. When issuing a certificate of public good under this section, the board shall give due consideration to all conditions in an existing state or local permit and shall harmonize the conditions in the certificate of public good with the existing permit conditions to the extent feasible.

(e) Notice. No less than 45 days prior to filing a petition for a certificate of public good under this section, the applicant shall serve written notice of an application to be filed with the board pursuant to this section to the legislative bodies and municipal and regional planning commissions in the communities in which the applicant proposes to construct or install facilities; the secretary of the agency of natural resources; the commissioner of the department of public service and its director for public advocacy; and the landowners of record of property adjoining the project sites. In addition, at least one copy of each application shall be filed with each of these municipal and regional planning commissions. Upon motion or otherwise, the public service board shall direct that further public or personal notice be provided if the board finds that such further notice will not unduly delay consideration of the merits and that additional notice is necessary for fair consideration of the application.

(f) Review period. Unless the public service board identifies that an application raises a significant issue, the board shall issue a final determination on an application filed pursuant to this section within 90 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 90 days of the date on which the clerk of the board notifies the applicant that the filing is complete. If the board rules that an application raises a significant issue, it shall issue a final determination on an application filed pursuant to this section within 180 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 180 days of the date on which the clerk of the board notifies the applicant that the filing is complete.

(g) Letter of intent. Nothing in this section shall be construed to prohibit an applicant from executing a letter of intent or entering into a contract before the issuance of a certificate of public good under this section, provided that the obligations under that letter of intent or contract are made subject to compliance with the requirements of this section.

(h) Exemptions from other law. An applicant using the procedures provided in this section shall not be required to obtain a permit or permit amendment or other approval under the provisions of chapter 117 of Title 24 or chapter 151 of Title 10 for the facilities subject to the application or to a certificate of public good issued pursuant to this section. Ordinances adopted pursuant to subdivision 2291(19) of Title 24 or a municipal charter that would otherwise apply to the construction or installation of facilities subject to this section are preempted. Disputes over jurisdiction under this section shall be resolved by the public service board, subject to appeal as provided by section 12 of this title. An applicant that has obtained or been denied a permit or permit amendment under the provisions of Title 24 or chapter 151 of Title 10 for the construction of a telecommunications facility may not apply for approval from the board for the same or substantially the same facility, except that an applicant may seek approval for a modification to such a facility.

(i) Sunset of board authority. Effective July 1, 2011, no new applications for certificates of public good under this section may be considered by the board.

(j)(1) Minor applications. The board may, subject to such conditions as it may otherwise lawfully impose, issue a certificate of public good in accordance with the provisions of this subsection and without the notice and hearings required by any provision other than subdivision (2) of this subsection if the board finds that such facilities will be of limited size and scope, and the petition does not raise a significant issue with respect to the substantive criteria of this section. If an applicant requests approval of multiple telecommunications facilities in a single application under this section, the board may issue a certificate of public good in accordance with the provisions of this subsection for all or some of the telecommunications facilities described in the petition.

(2)(A) Any party seeking to proceed under the procedures authorized by this subsection shall file a proposed certificate of public good and proposed findings of fact with its petition, and provide notice and a copy of the petition, proposed certificate of public good, and proposed findings of fact to the commissioner of the department of public service and its director for public advocacy, the secretary of the agency of natural resources, and each of the legislative bodies and municipal and regional planning commissions in the communities in which the applicant proposes to construct or install facilities. The applicant shall give written notice of the proposed certificate to the landowners of record of property adjoining the project site or sites unless the board has previously determined on request of the applicant that good cause exists to waive or modify the notice requirement with respect to such landowners. Such notice shall request comment to the board within 21 days of the notice on the question of whether the petition raises a significant issue with respect to the substantive criteria of this section. If the board finds that a petition raises a significant issue with respect to the substantive criteria of this section, the board shall hear evidence on any such issue.

(B) Any waiver or modification of notice to adjoining landowners under this subsection shall be based on a determination that the landowners subject to the waiver or modification could not reasonably be affected by one or more of the proposed facilities, and that notice to such landowners would constitute a significant administrative burden without corresponding public benefit.

(C) If the board accepts a request to consider an application under the procedures of this subsection, then unless the public service board subsequently determines that an application raises a significant issue, the board shall issue a final determination on an application filed pursuant to this subsection within 45 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 45 days of the date on which the clerk of the board notifies the applicant that the filing is complete. If, subsequent to acceptance of an application under this subsection, the board rules that an application raises a significant issue, it shall issue a final determination on an application filed pursuant to this subsection within 90 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 90 days of the date on which the clerk of the board notifies the applicant that the filing is complete.

(D) If the board denies a request to consider an application under the procedures of this subsection, a filing made under this subsection that the board has found to be complete shall be deemed to satisfy notice requirements of subsection (e) of this section, and the periods stated under subsection (f) of this section shall run from the date of the board's denial of such request.

(k) Rules. The public service board may issue rules or orders implementing and interpreting this section. In developing such rules and orders, the board shall seek to simplify the application and review process as appropriate and may by rule or order waive the requirements of this section that the board determines are not applicable to telecommunications facilities of limited size or scope. Determination by the board that a petition raises a substantial issue with regard to one or more substantive criteria of this section shall not prevent the board from waiving other substantive criteria that it has determined are not applicable to such a telecommunications facility. (Added 2007, No. 79, § 17, eff. June 9, 2007; 2009, No. 54, § 44, eff. June 1, 2009.)


State Codes and Statutes


Back To Homepage

State Codes and Statutes

Statutes > Vermont > Title-30 > Chapter-5 > 248a

§ 248a. Certificate of public good for communications facilities

(a) Certificate. Notwithstanding any other provision of law, if the applicant seeks approval for the construction or installation of telecommunications facilities that are to be interconnected with other telecommunications facilities proposed or already in existence, the applicant may obtain a certificate of public good issued by the public service board under this section, which the board may grant if it finds that the facilities will promote the general good of the state consistent with subsection 202c(b) of this title. A single application may seek approval of one or more telecommunications facilities.

(b) Definitions. For the purposes of this section:

(1) "Telecommunications facility" means a communications facility that transmits and receives signals to and from a local, state, national, or international network used primarily for two-way communications for commercial, industrial, municipal, county, or state purposes and any associated support structure that is proposed for construction or installation which is primarily for communications purposes, and any ancillary improvements that are proposed for construction or installation and are primarily intended to serve the communications facilities or support structure.

(2) An applicant may seek approval of construction or installation of a telecommunications facility whether or not the telecommunications facility is attached to an existing structure.

(c) Findings. Before the public service board issues a certificate of public good under this section, it shall find that:

(1) The proposed facility will not have an undue adverse effect on aesthetics, historic sites, air and water purity, the natural environment, and the public health and safety, with due consideration having been given to the relevant criteria specified in subsection 1424a(d) and subdivisions 6086(a)(1) through (8) and (9)(K) of Title 10.

(2) Unless there is good cause to find otherwise, substantial deference has been given to the land conservation measures in the plans of the affected municipalities and the recommendations of the municipal legislative bodies and the municipal and regional planning commissions regarding the municipal and regional plans, respectively. Nothing in this section or other provision of law shall prevent a municipal body from basing its recommendations on an ordinance adopted under 24 V.S.A. § 2291(19) or bylaw adopted under 24 V.S.A. chapter 117 by the municipality in which the facility is located.

(d) Existing permits. When issuing a certificate of public good under this section, the board shall give due consideration to all conditions in an existing state or local permit and shall harmonize the conditions in the certificate of public good with the existing permit conditions to the extent feasible.

(e) Notice. No less than 45 days prior to filing a petition for a certificate of public good under this section, the applicant shall serve written notice of an application to be filed with the board pursuant to this section to the legislative bodies and municipal and regional planning commissions in the communities in which the applicant proposes to construct or install facilities; the secretary of the agency of natural resources; the commissioner of the department of public service and its director for public advocacy; and the landowners of record of property adjoining the project sites. In addition, at least one copy of each application shall be filed with each of these municipal and regional planning commissions. Upon motion or otherwise, the public service board shall direct that further public or personal notice be provided if the board finds that such further notice will not unduly delay consideration of the merits and that additional notice is necessary for fair consideration of the application.

(f) Review period. Unless the public service board identifies that an application raises a significant issue, the board shall issue a final determination on an application filed pursuant to this section within 90 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 90 days of the date on which the clerk of the board notifies the applicant that the filing is complete. If the board rules that an application raises a significant issue, it shall issue a final determination on an application filed pursuant to this section within 180 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 180 days of the date on which the clerk of the board notifies the applicant that the filing is complete.

(g) Letter of intent. Nothing in this section shall be construed to prohibit an applicant from executing a letter of intent or entering into a contract before the issuance of a certificate of public good under this section, provided that the obligations under that letter of intent or contract are made subject to compliance with the requirements of this section.

(h) Exemptions from other law. An applicant using the procedures provided in this section shall not be required to obtain a permit or permit amendment or other approval under the provisions of chapter 117 of Title 24 or chapter 151 of Title 10 for the facilities subject to the application or to a certificate of public good issued pursuant to this section. Ordinances adopted pursuant to subdivision 2291(19) of Title 24 or a municipal charter that would otherwise apply to the construction or installation of facilities subject to this section are preempted. Disputes over jurisdiction under this section shall be resolved by the public service board, subject to appeal as provided by section 12 of this title. An applicant that has obtained or been denied a permit or permit amendment under the provisions of Title 24 or chapter 151 of Title 10 for the construction of a telecommunications facility may not apply for approval from the board for the same or substantially the same facility, except that an applicant may seek approval for a modification to such a facility.

(i) Sunset of board authority. Effective July 1, 2011, no new applications for certificates of public good under this section may be considered by the board.

(j)(1) Minor applications. The board may, subject to such conditions as it may otherwise lawfully impose, issue a certificate of public good in accordance with the provisions of this subsection and without the notice and hearings required by any provision other than subdivision (2) of this subsection if the board finds that such facilities will be of limited size and scope, and the petition does not raise a significant issue with respect to the substantive criteria of this section. If an applicant requests approval of multiple telecommunications facilities in a single application under this section, the board may issue a certificate of public good in accordance with the provisions of this subsection for all or some of the telecommunications facilities described in the petition.

(2)(A) Any party seeking to proceed under the procedures authorized by this subsection shall file a proposed certificate of public good and proposed findings of fact with its petition, and provide notice and a copy of the petition, proposed certificate of public good, and proposed findings of fact to the commissioner of the department of public service and its director for public advocacy, the secretary of the agency of natural resources, and each of the legislative bodies and municipal and regional planning commissions in the communities in which the applicant proposes to construct or install facilities. The applicant shall give written notice of the proposed certificate to the landowners of record of property adjoining the project site or sites unless the board has previously determined on request of the applicant that good cause exists to waive or modify the notice requirement with respect to such landowners. Such notice shall request comment to the board within 21 days of the notice on the question of whether the petition raises a significant issue with respect to the substantive criteria of this section. If the board finds that a petition raises a significant issue with respect to the substantive criteria of this section, the board shall hear evidence on any such issue.

(B) Any waiver or modification of notice to adjoining landowners under this subsection shall be based on a determination that the landowners subject to the waiver or modification could not reasonably be affected by one or more of the proposed facilities, and that notice to such landowners would constitute a significant administrative burden without corresponding public benefit.

(C) If the board accepts a request to consider an application under the procedures of this subsection, then unless the public service board subsequently determines that an application raises a significant issue, the board shall issue a final determination on an application filed pursuant to this subsection within 45 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 45 days of the date on which the clerk of the board notifies the applicant that the filing is complete. If, subsequent to acceptance of an application under this subsection, the board rules that an application raises a significant issue, it shall issue a final determination on an application filed pursuant to this subsection within 90 days of its filing or, if the original filing did not substantially comply with the public service board's rules, within 90 days of the date on which the clerk of the board notifies the applicant that the filing is complete.

(D) If the board denies a request to consider an application under the procedures of this subsection, a filing made under this subsection that the board has found to be complete shall be deemed to satisfy notice requirements of subsection (e) of this section, and the periods stated under subsection (f) of this section shall run from the date of the board's denial of such request.

(k) Rules. The public service board may issue rules or orders implementing and interpreting this section. In developing such rules and orders, the board shall seek to simplify the application and review process as appropriate and may by rule or order waive the requirements of this section that the board determines are not applicable to telecommunications facilities of limited size or scope. Determination by the board that a petition raises a substantial issue with regard to one or more substantive criteria of this section shall not prevent the board from waiving other substantive criteria that it has determined are not applicable to such a telecommunications facility. (Added 2007, No. 79, § 17, eff. June 9, 2007; 2009, No. 54, § 44, eff. June 1, 2009.)


Disclaimer
There is no confidential attorney-client relationship formed by using Laws.com website and information provided on this site is not legal advice. For legal advice, please contact your attorney. Attorneys listed on this website are not referred or endorsed by this website. By using Laws.com you agree to Laws.com Terms Of Use.
Copyright © 2017 Laws.com | All rights reserved

Loading..

Close Window

Loading, Please Wait!

This may take a second or two.