State Codes and Statutes

Statutes > Utah > Title-38 > Chapter-11 > 38-11-203

38-11-203. Disbursements from the fund -- Limitations.
(1) A payment of any claim upon the fund by a qualified beneficiary shall be made onlyupon an order issued by the director finding that:
(a) the claimant was a qualified beneficiary during the construction on a residence;
(b) the claimant complied with the requirements of Section 38-11-204; and
(c) there is adequate money in the fund to pay the amount ordered.
(2) A payment of a claim upon the fund by a laborer shall be made only upon an orderissued by the director finding that:
(a) the laborer complied with the requirements of Subsection 38-11-204(7); and
(b) there is adequate money in the fund to pay the amount ordered.
(3) (a) An order under this section may be issued only after the division has compliedwith the procedures established by rule under Section 38-11-105.
(b) The director shall order payment of the qualified services as established by evidence,or if the claimant has obtained a judgment, then in the amount awarded for qualified services inthe judgment to the extent the qualified services are attributable to the owner-occupied residenceat issue in the claim.
(c) The director shall order payment of interest on amounts claimed for qualified servicesbased on the current prime interest rate at the time payment was due to the date the claim isapproved for payment except for delays attributable to the claimant but not more than 10% perannum.
(d) The rate shall be the Prime Lending Rate as published in the Wall Street Journal onthe first business day of each calendar year adjusted annually.
(e) The director shall order payment of costs in the amount stated in the judgment. If thejudgment does not state a sum certain for costs, or if no judgment has been obtained, the directorshall order payment of reasonable costs as supported by evidence. The claim application fee asestablished by the division pursuant to Subsection 38-11-204(1)(b) is not a reimbursable cost.
(f) If a judgment has been obtained with attorneys' fees, notwithstanding the amountstated in a judgment, or if no judgment has been obtained but the contract provides for attorneys'fees, the director shall order payment of attorneys' fees not to exceed 15% of qualified services. If the judgment does not state a sum for attorneys' fees, no attorneys' fees will be paid by thedirector.
(4) (a) Payments made from the fund may not exceed $75,000 per construction project toqualified beneficiaries and laborers who have claim against the fund for that construction project.
(b) If claims against the fund for a construction project exceed $75,000, the $75,000 shallbe awarded proportionately so that each qualified beneficiary and laborer awarded compensationfrom the fund for qualified services shall receive an identical percentage of the qualifiedbeneficiary's or laborer's award.
(5) Subject to the limitations of Subsection (4), if on the day the order is issued there areinadequate funds to pay the entire claim and the director determines that the claimant hasotherwise met the requirements of Subsection (1) or (2), the director shall order additionalpayments once the fund meets the balance limitations of Section 38-11-206.

Amended by Chapter 42, 2004 General Session